Clicky

Legal Notices, July 1, 2022

NOTICE OF INVITATION TO BIDS FROM THE CITY OF ENCINITAS San Elijo Lagoon Bridge Abutment Backfill Repairs CS22E This is to announce that the City of Encinitas will be receiving ONLY ELECTRONIC BIDDS via the online bidding service PlanetBids by 2:00 p.m. on July 26, 2022 at that time the ELECTRONIC OFFERS open to the public and read. The results will be published on PlanetBids immediately after the end of the bid opening. Bidders do not have to be present at the opening of bids, but can attend if they wish. The City Street address is as follows: City of Encinitas 505 S. Vulcan Avenue Encinitas, California 92024 WORK TO BE PERFORMED: Work to be performed generally includes: Work to be performed is located at the San Elijo Bridge at S Coast Hwy 101, Encinitas, CA 92024. Works to be performed include traffic control, supply coordination, site preparation, shoring and excavation aft of the northeast bridge abutment, geofabric installation, backfill, metal truss guardrail upgrade and site reconstruction. The contractor will carry out the proposed work in its entirety. Should details or details be omitted from the Contractual Documents which are essential to their functional completeness, it is the contractor’s responsibility to provide and install such details or to request such details from the City Engineer to enable this to be done after the proposed work has been completed, the work will be acceptable and ready for use. Engineer’s Estimate – $275,000 (base bid) LOWEST RESPONSIBILITY AND ACCOUNTABILITY BIDDER: All bids to be compared based on the city engineer’s estimate of the amount of work to be done and the unit prices offered by the bidder. If the order is awarded, the order will be awarded to the reaction sfastest and most responsible bidder. Under Public Contract Code Section 1103, a “responsible bidder” means a bidder who has demonstrated the attributes of good faith, quality, suitability, capacity and experience to perform this public works contract satisfactorily. OBTAINING CONTRACTUAL DOCUMENTS: The website for this listing and related documents is: PlanetBids (http://www.encinitasca.gov/bids). All application materials and project correspondence will be published on the PlanetBids website. It is the responsibility of the proposed bidders to regularly check the website for information updates and bid clarifications as well as any supplements. In order to place a bid, a bidder must be a registered seller with the City of Encinitas. To register as a bidder, go to the following link (http://www.encinitasca.gov/bids) and then proceed to the Register as a bidder link. Contract materials are available after June 28, 2022 at the Engineering Counter at City Hall at 505 S. Vulcan Ave., Encinitas, CA 92024 at a non-refundable rate of $50.00 per set. Consistent with California Contract Code Section 20103.7, electronic copies will be made available to bid committees and contractors for series of contractor schedules upon request. The City makes no representations as to the accuracy of any contract documents received from third party design rooms and the Contractor accepts any bid documentation from any third party at its own risk. Should contractors choose to collect project plans and specifications from City Hall, contractors are still responsible for obtaining all addendums for the project and for signing and submitting all addenda with their bid. Any Contractor failing to receive all Supplements ni Failure to confirm by signing and submitting any addenda with his bid will be deemed a non-responding bidder and his bid will be rejected. PREVIOUS WAGE AND ENFORCEMENT COMPLIANCE: This is a prevailing wage project and prevailing wage rates for that location and project shall apply, as determined by the Director of Industrial Relations, pursuant to Labor Code Section 1770 et seq. Seq. The prevailing wage determination for this project is 2022. A copy of the prevailing wage rates will be posted by the contractor on site. A list of prevailing wage rates can be found at City Offices or on the Internet at http://www.dir.ca.gov/Public-Works/Prevailing-Wage.html. The successful bidder must pay at least the wage rates set out in this table. Records of certified payslips will be maintained by the contractor and copies of certified payslips will be sent electronically to the Department of Labor Relations and delivered to the City at the end of each month throughout the duration of the project. The project is subject to monitoring and enforcement of compliance by the Department of Industrial Relations. Subject to the exceptions set out in Section 1771.1 of the Labor Code, subject to the requirements of Section 4104 of the Public Procurement Code, contractors or subcontractors shall not be entitled to participate in bids, be listed in a bid bid or participate in the execution of any public works contract , as defined by law, unless currently registered and qualified to perform public works under Section 1725.5 of the Labor Code. The City shall not make any offer or enter into any contract or subcontract without proof of current registration of the Auf contractor or subcontractor to perform public works under Section 1725.5. For more information, visit http://www.dir.ca.gov/Public-Works/Certified-Payroll-Reporting.html COMPLIANCE WITH LABOR LAWS: The prime contractor is responsible for ensuring compliance with all applicable Labor Code, including but not limited to limited to Section 1777.5. See also INFORMATION AND INSTRUCTIONS FOR BIDDERS in the tender documents for additional bid information and requirements. City of Encinitas BY: Abraham Bandegan, P.E. for Jill Bankston, P.E. City Engineer DATE: _3-9-2022. END OF NOTICE OF INVITATION OF OFFERS 07/01/2022, 07/08/2022 CN 26719

CITY OF ENCINITAS DEVELOPMENT SERVICES DEPARTMENT LEGAL NOTICE REGARDING ENVIRONMENTAL REVIEW AND COMMENT PERIOD Public Review Period: June 30, 2022 to August 1, 2022 This is to announce that a 30-day public review and comment period has been established in accordance with the California Environmental Quality Act (CEQA) for a draft mitigated negative statement prepared for the proposed project as identified below and located in the city of Encinitas. PROJECT NAME: La Costa Hotel CASE NUMBER: MULTI-002750-2018; USE-002671-2018; DR-002670-2018; CDP-002672-2018 (18-188 MIN/DR/CDP) APPLICANT: DM La Costa Avenue, LLC. LOCATION: 516 La Costa Avenue (APN 216-030-48), Municipality of Leucadia DESCRIPTION: DM La Costa Avenue LLC. (Applicant) proposes the development of a 17-room boutique hotel with a full-service restaurant with alcohol service and outdoor events, new monument signage and a temporary construction trailer on site on approximately 1.18 hectares in the Leucadia- Municipality of the city before Encinitas. The hotel units would be located in nine detached bungalow structures. A total of 41 parking spaces are planned, including four e-charging spaces. In addition, a loading space, four motorcycle parking spaces and two bicycle parking spaces are planned. Proposed amenities include a pool, spas, lounge seating, and walking paths. The project site is designated within the Visitor Serving Commercial (VSC) Zone and within the Cultural Natural Resources Overlay Zone, the Scenic/Visual Corridor Overlay Zone and within the appellate jurisdiction of the Coastal Zone Coastal Commission. This land use and zoning classification is intended to support commercial uses. Municipal approval of a minor use permit, a design review permit and a coastal development permit ng (MULTI-002750-2018; USE-002671-2018; DR-002670-2018; CDP-002672-2018 (18-188 MIN/DR/CDP) will ENVIRONMENTAL STATUS: The City conducted an initial environmental study that found that mitigation measures are required and that there would be no significant environmental impacts from the proposed project. Therefore, an attenuated negative statement is recommended for acceptance Written comments on the adequacy of the draft mitigated negative statement must be received by the Development Services Department at the address below by 5:00 p.m. on August 1, 2022. A final environmental document, which includes public input, will then be submitted for consideration by decision-making authorities The draft of the toned down negative statement and the first environmental study can be found on the city’s website at un ter https://encinitasca.gov/I-Want-To/Public-Notices/Development-Services-Public-Notices under “Environmental Notices”. Please contact the planning department staff below to review other supporting documents and the project application. This draft mitigated negative statement can also be viewed at the Encinitas Library (540 Cornish Dr, Encinitas, CA 92024) and the Cardiff-by-the-Sea Library (2081 Newcastle Ave, Cardiff, CA 92007). For more information, please contact Andrew Maynard, Senior Planner at 760.633-2718 or email at [email protected] or the Planning Department at 760-633-2710 or [email protected]. 07/01/2022 CN 26713

CITY OF ENCINITAS DEVELOPMENT SERVICES DEPARTMENT MOBILITY ELEMENT OF THE GENERAL PLAN NOTICE OF COMMUNITY WORKSHOP In compliance with the Americans with Disabilities Act/Section 504 Rehabilitation Act of 1973 and Title VI, this agency is a public equal opportunity entity and does not discriminate on the basis of race , color, race, national origin, gender, religion, veteran status, or physical or mental disability in employment or the provision of services. If you require special assistance to attend this meeting, please contact the Development Services Department at (760) 633-2710 at least 72 hours prior to the meeting. The City of Encinitas is preparing the Draft Mobility Element Update. The second community workshop for the Mobility Element Update will be held on: Thursday, July 21, 2022 6:00 p.m. – 8:00 p.m. Encinitas Community and Senior Center 1140 Oakcrest Park Drive Encinitas, CA 92024 This workshop provides an opportunity for community members Learn more about the Encinitas Mobility Element Update and provide key feedback on goals and policies and the potential citywide network and street classifications. We want to hear from all types of mobility users, including pedestrians, cyclists, road users and drivers. For more information on the Mobility Element Update, visit the project webpage on the city’s website: encinitasca.gov/Mobility-Element. For more information, please contact Evan Jedynak, Associate Planner, by email at [email protected] or by phone at (760) 633-2686. Future Opportunities to Participate The public and interested parties are also encouraged to attend future public sessions. To stay informed of project updates and upcoming meetings, visit encinitasca.gov/Home/City-Updates to sign up to receive city newsletters and e-alerts. Select “Mobility Element” and any other topic that interests you. La presentación sera en inglés. Llame al (760) 943-2150 antes del 15 de Julio si necesita servicios de tra ducción durante la presentación. Para obtener más information, comuníquese with Evan Jedynak, Planificador Asociado por correo electrónico [email protected]. Para assistant en español, por favor lame al (760) 943-2150. 07/01/2022 CN 26712

CITY OF CARLSBAD NOTICE OF PUBLIC HEARING IS HEREBY ISSUED that the City Council of Carlsbad will hold a public hearing at 5:00 pm at the Council Chamber, 1200 Carlsbad Village Drive, Carlsbad, California. on Tuesday, July 12, 2022 to receive, submit and accept the annual monitoring report for fiscal year 2020-21 for the City of Carlsbad General Plan/Growth Management Program (GMP)/Citywide Facility and Improvement Plan (CFIP), to be completed pursuant to Section 21.90.130 of the Karlovy Vary City Code was drawn up. As discussed below, the City Council may also adopt resolutions with exceptions to vehicle service levels and compliance determinations of performance standards. This monitoring report includes analysis of development activities, compliance with residential development limits and quadrant boundaries, analysis of adequacy of facilities and improvements, including discussion of compliance with citywide plan performance standards for facilities and improvements for administrative facilities, libraries, wastewater treatment capacity, parks, and Drainage, circulation, fire, open spaces, schools, sewage collection systems and water distribution systems and adopting GMP consistency results. The City Council will also consider the recommendations of the Transport and Mobility Commission made at its public hearing on 6 June 2022 presenting the Transport section of the GMP report’s Growth Management Plan and taking into account the findings that two road facilities were found would be deficient and may justify an exemption. The City Council may also take actions related to compliance with the city’s circulation performance standards, which include potential determinations of vehicle level of service (LOS) deficiencies and vehicle LOS-off Measures according to general plan mobility element policy 3-P.9 may include acceptance of CEQA exemptions. Anyone wishing to comment on this proposal is invited to attend the public hearing. The personnel report will be available on or after Friday, July 8, 2022. If you have any questions, please contact Eric Lardy in the Planning Department at (442) 339-2712 or [email protected]. The meeting can be viewed online at https://www.carlsbadca.gov/city-hall/meetings-agendas or on the city’s cable channel. In addition, written comments may be submitted to the City Council during or prior to the hearing by U.S. mail to the attention of the Office of the City Clerk, 1200 Carlsbad Village Drive, Carlsbad, CA 92008 or by email to [email protected]. If you challenge this Annual Surveillance Report, vehicle exceptions, findings, or City Council actions in court, you may be limited to raising only those issues that you or another person raise at the public hearing described in this notice or in a written court hearing Correspondence served on the City of Carlsbad, Attn: City Clerk’s Office, 1200 Carlsbad Village Drive, Carlsbad, CA 92008, at or prior to the Public Hearing. PUBLICATION: July 1, 2022 CITY AGREEMENT OF THE CITY OF KARLSBAD 07/01/2022 CN 26711

CITY OF CARLSBAD NOTICE OF PUBLIC HEARING IS HEREBY MISSED TO YOU because your interest may be affected that the City Council of Carlsbad will hold a public hearing at the Council Chamber, 1200 Carlsbad Village Drive, Carlsbad, California at 5 p.m. July 2022 to consider approving amendments to the City’s Density Bonus Ordinance (ZCA 2020-0001/LCPA 2020-0005) and specifically described as: Enacting an ordinance confirming receipt of the California Coastal Commission’s Certification Order of Local Coastal Program Amendments ( LCPA 2020-0005), including the Commission’s proposed changes to the Zoning Ordinance and Local Coastal Scheme. Anyone wishing to comment on this proposal is invited to attend the public hearing. Copies of the employee report are available until Friday, July 8, 2022. If you have any questions, please contact Eric Lardy in the Planning Department at (442) 339-2712 or [email protected]. The meeting can be viewed online at https://www.carlsbadca.gov/city-hall/meetings-agendas or on the city’s cable channel. In addition, written comments may be submitted to the City Council during or prior to the hearing by U.S. mail to the attention of the Office of the City Clerk, 1200 Carlsbad Village Drive, Carlsbad, CA 92008 or by email to [email protected]. If you contest the Zoning Ordinance and Local Coastal Program changes in court, you may be limited to raising only those issues raised by you or another person at the public hearing described in this notice or in a written letter to the City of Carlsbad , Attn : City Clerk’s Office, 1200 Carlsbad Village Drive, Carlsbad, CA 92008, and at or before the public hearing. CASE FILE: ZCA 2020-0001/ LCPA 2020-0005 CASE NAME: Density Bonus Amendments 2020 PUBLICATION: July 1, 2022 CITY AGREEMENT OF THE CITY OF KARLSBAD 07/01/2022 CN 26710

CITY OF CARLSBASD PUBLIC HEARING NOTICE IS HEREBY MISSED TO YOU because your interest may be affected that the City Council of Carlsbad will hold a public hearing at the Council Chamber, 1200 Carlsbad Village Drive, Carlsbad, California at 5 p.m. Tuesday, March 12. July 2022 to consider approving the City Regulations for Additional Housing Units (MCA 2020-0001/ZCA 2020-0002/AMEND 2020-0005/LCPA 2020-0006) and specifically described as: Establishing Regulations Acknowledging Receipt of Local Coastal Program Amendment (LCPA 2020-0006) by the California Coastal Commission, including proposed changes to the Zoning Ordinance and the Local Coastal Program. Anyone wishing to comment on this proposal is invited to attend the public hearing. The employee report will be available on or before Friday, July 8, 2022. If you have any questions, please contact Eric Lardy in the Planning Department at (442) 339-2712 or [email protected]. The meeting can be viewed online at https://www.carlsbadca.gov/city-hall/meetings-agendas or on the city’s cable channel. In addition, written comments may be submitted to the City Council during or prior to the hearing by U.S. mail to the attention of the Office of the City Clerk, 1200 Carlsbad Village Drive, Carlsbad, CA 92008 or by email to [email protected]. If you contest the Zoning Ordinance and Local Coastal Program changes in court, you may be limited to raising only those issues raised by you or another person at the public hearing described in this notice or in a written letter to the City of Carlsbad , Attn : City Clerk’s Office, 1200 Carlsbad Village Drive, Carlsbad, CA 92008, at or before the public hearing. CASE FILE: MCA 2020-0001/ZCA 2020-0002/AMEND 2 020-0005/LCPA 2020-0006 CASE NAME: Accessory Dwelling Unit Amendments 2020 PUBLICATION: 1 JULY 2022 CITY COUNCIL OF KARLSBAD CITY 07/01/2022 CN 26709

ANNOUNCEMENT: INVITATION TO BID AT CITY OF ENCINITAS, FY2021-2022 COVE RUB AND MUD LINER REHABILITATION PROJECT (CS22A) This is to announce that the City of Encinitas is accepting ELECTRONIC BIDDING ONLY via the PlanetBids online bidding service until 2:00 p.m , on July 19, 2022. At that time, the ELECTRONIC COMMANDMENTS will be made publicly available and read. The results will be published on PlanetBids immediately after the end of the bid opening. Bidders do not have to be present at the opening of bids. The results of the bids for the PROJECT PAVEMENT REHABILITATION OVERLAY AND SURRY SEAL for FY 2021-2022 are available from 14:00 only in PlanetBids. on 07/19/2022. WORKS TO BE PERFORMED: The works to be carried out generally include: asphalt overlays, mud sealing, surface and full repairs, crack sealing, asphalt paving milling, concrete ramp removal and replacement, traffic detector reconstruct grinding, removal and replacement of lane strips and markings, adjustment of manholes and valves, repair of Concrete gutters, installation of air conditioning, removal and replacement of food capsules and other related work not mentioned above. Engineer’s Estimate – $1,300,000 (base bid only) LOWEST RESPONSIVENESS AND ACCOUNTABILITY BIDDER: All bids to be compared based on the city engineer’s estimate of the amount of work to be done and the unit price the bidder will bid. The contract, if awarded, will be awarded to the most responsive and responsible bidder. Pursuant to Public Contract Code Section 1103, a “Responsible Bidder” means a bidder who has demonstrated the attributes of good faith, quality, suitability, capacity and experience to tender that public Ba carry out the order satisfactorily. OBTAINING CONTRACTUAL DOCUMENTS: The website for this listing and related documents is: PlanetBids (http://www.encinitasca.gov/bids). All application materials and project correspondence will be published on the PlanetBids website. It is the responsibility of Proposed Bidders to check the website periodically for updated information and explanations of offers and supplements. In order to place a bid, a bidder must be a registered seller with the City of Encinitas. To register as a bidder, go to the following link (http://www.encinitasca.gov/bids) and then proceed to the Register as a bidder link. Consistent with California Contract Code Section 20103.7, electronic copies will be made available to bid committees and contractors for series of contractor schedules upon request. The City makes no representations as to the accuracy of any contract documents received from third party design rooms and the Contractor accepts any bid documentation from any third party at its own risk. Contractors are responsible for obtaining all addenda for the project and for signing and submitting all addenda with their bid. Any Contractor who fails to acknowledge receipt of all Addendums by signing and submitting all Addendums with their bid will be deemed a Non-Responding Bidder and their bid will be rejected. EXISTING WAGE AND ENFORCEMENT COMPLIANCE: This is a prevailing wage project and prevailing wage rates for that location and project, as determined by the Director of Industrial Relations, pursuant to Labor Code Section 1770 et seq. Seq. The applicable wage determination for this project is 2022-1. A copy of the applicable wage rates will be posted by the contractor on the construction site. A list of Current wage rates are available at city offices or on the Internet at http://www.dir.ca.gov/Public-Works/Prevailing-Wage.html. The successful bidder must pay at least the wage rates set out in this table. Records of certified payslips will be maintained by the contractor and copies of certified payslips will be sent electronically to the Department of Labor Relations and delivered to the City at the end of each month throughout the duration of the project. The project is subject to compliance and monitoring and enforcement by the Department of Industrial Relations. Subject to the exceptions set out in Section 1771.1 of the Labor Code, subject to the requirements of Section 4104 of the Public Procurement Code, contractors or subcontractors shall not be entitled to participate in bids, be listed in a bid bid or participate in the execution of any public works contract , as defined by law, unless currently registered and qualified to perform public works under Section 1725.5 of the Labor Code. The City shall not accept any bid, contract or subcontract entered into without proof of current registration of the contractor or subcontractor to perform public works in accordance with Section 1725.5. For more information, visit http://www.dir.ca.gov/Public-Works/Certified-Payroll-Reporting.html COMPLIANCE WITH LABOR LAWS: The prime contractor is responsible for ensuring compliance with all applicable Labor Code, including but not limited to limited to Section 1777.5. See also INFORMATION AND INSTRUCTIONS FOR BIDDERS in the tender documents for additional bid information and requirements. City of Encinitas BY: Jill T. Bankston, P.E. City Engineer DATE: June 23, 2022 END OF NOTICE OF INVITATION OF OFFERS 07/01/2022, 07/08/2022 CN 26706

CITY OF ENCINITAS PUBLIC ANNOUNCEMENT OF DECREE ADOPTION DECREE NO. 2022-08 IT IS HEREBY NOTIFIED that the City Council for the City of Encinitas issued Ordinance No. 2022-08 entitled “An Ordinance of the City Council of the City of Encinitas, California Aendering Chapter 9.30 Firearms to Add Sections 9.30.030 and 9.30. 040 of the Encinitas Municipal Code regarding unserialized, unfinished firearm frames or receivers and unserialized firearms. Ordinance 2022-08 adds Chapter 9.30 Firearms to the Encinitas Municipal Code and includes: Section 9.30.030 Definitions for Regulating Unserialized Unfinished Firearm Frames or Casings and Unserialized Firearms; and Section 9.30.040. Rules for Non-Serialized, Unfinished Firearm Frames or Cases, and Non-Serialized Firearms (For purposes of this section, any reference to firearms, frames, cases, unfinished frames, or unfinished cases includes those made by 3D printing). Section 9.30.040 includes, but is not limited to, regulations and prohibitions relating to possession, purchase, transportation, receipt, sale, offer for sale, transfer and offer for transfer of non-serialized unfinished firearm frames or receivers and non-serialized firearms. Ordinance 2022-08 was introduced at the June 8, 2022 Ordinary City Council Session and was adopted at the June 22, 2022 Ordinary City Council Session by the following vote: YES: Hinze, Kranz, Lyndes, Mosca; No None; ABSTAINMENT: None. ABSENT: Blakespear. The ordinance is on file at the City Clerk’s office at 505 South Vulcan Avenue and is available for inspection between 8:00 a.m. and 6:00 p.m. and 5:00 p.m. In accordance with the Americans with Disabilities Act/Section 504 Rehabilitation Act of 1973 and Title VI, this agency is a public entity for C Equal opportunity and does not discriminate on the basis of race, color, ethnic origin, national origin, sex, religion or veteran status or physical or mental disability in employment or the provision of services. If you require special assistance to attend this meeting, please contact the City Clerk’s Office at 760-633-2601 at least 72 hours prior to the meeting. /Kathy Hollywood, Town Clerk 7/1/2022 CN 26703

DECISION OF THE CITY OF CARLSBAD NO. 2022-115 AN RESOLUTION OF THE CITY COUNCIL FOR THE CITY OF CARLSBAD, CALIFORNIA INITIALIZING PROCEEDINGS, APPROVING THE PRELIMINARY ENGINEERING REPORT FOR THE 2022-23 FISCAL YEAR AND SCHEDULING A PUBLIC HEARING FOR JULY 12, 2022 FOR THE ANNUAL REVIEW IN REVIEW AND COUNTRYSIDE DISTRICT NO. 2, A SPECIAL ASSESSMENT DISTRICT WHILE the City Council for the City of Carlsbad, California previously established a special assessment district under the provisions of the California Streets and Highways Code Section 22500 et seq., known as the Street Lighting and Landscaping District Designated No. 2 of the City of Carlsbad (“Rating District”); and WHEREAS the Rating District is an existing Rating District in which no increase in ratings is proposed as defined in Article XIIID of the California Constitution (Proposition 218) and the Proposition 218 Omnibus Implementation Act (California Government Code Section 53750 et seq.). , and is therefore exempt from the procedures and requirements of Proposition 218 under Article XIIID, Section 5, Subsection (a) of the California Constitution; and WHEREAS the City Council wishes to initiate a process to provide for the annual collection of tax amounts for fiscal year 2022-23 to cover the annual cost of maintenance of improvements defined as existing street lighting, medium landscaping and street trees (“ Improvements” ), within the assessment district; and WHEREAS a preliminary engineer’s report (the “Report”) has been prepared and will be submitted to the City Council and attached as Exhibit A as required by law and the City Council’s desire to proceed with the annual filing process; and WHERE to retain Ending improvements must consist of all originally identified and authorized improvements plus certain new and additional improvements; and WHEREAS the City Council has carefully reviewed and reviewed the report submitted and is satisfied with all the items and documents contained therein and is satisfied that the preliminary assessments have been distributed according to the benefits from the expected improvements maintained as set out in the report. THEREFORE IT IS NOW RESOLVED by the City Council for the City of Carlsbad, California as follows: 1. That the above recitations are true and correct. 2. That public interest and expediency so require and it is the intention of this Legislative Body to collect and collect estimates of the annual costs and expenses of servicing and/or maintaining the improvements for the assessment district with the improvements in general pay as follows: the maintenance of certain street lighting improvements, street trees and median landscaping improvements as set forth and described in the report. The proposed new improvements to be serviced and maintained generally through new developments within the assessment district are described as follows: the maintenance of certain additional street lighting improvements and additional landscaping improvements, including the replacement of street trees and landscaping resource improvements, all as set out and in the report described. 3. That the improvements will directly benefit the properties within the boundaries of the assessment district previously declared by the Legislature as the area to benefit from the improvement, as identified and referenced in the boundary map previously approved by the City Council, a Ko pie of which is in the town clerk’s office and is open to the public and bears the name of that assessment district. 4. That the improvements to Harris & Personnel instructed to prepare and submit the report, which generally includes: A. Plans and specifications describing the general nature, location and scope of the I improvements within the assessment district; B. A chart for the appraisal district showing the area and properties proposed for appraisal; C. An estimate of the cost of upkeep and/or maintenance of the improvements for the assessment district for the fiscal year beginning July 1, 2022 and ending June 30, 2023; D. An assessment of the estimated cost of maintenance and/or upkeep, assessing the net amount for all assessable properties and/or parcels within the assessment district in proportion to the benefits received. 5. That the submitted report be provisionally approved and ordered to be placed in the town clerk’s office as a permanent record and remain open for public inspection. Reference is made to the report for a full and detailed description of the improvements to be retained, the boundaries of the assessment precinct and all zones within it, and the proposed assessments on assessable properties and parcels within the assessment precinct. The rating district is an existing rating district in which no increase in ratings is proposed as defined by Article XIIID of the California Constitution (Proposition 218) and the Proposition 218 Omnibus Implementation Act. 6. It is hereby announced that a public hearing is scheduled for 5:00 p.m. at the City Council Chambers at 1200 Carlsbad Village Drive in Carlsbad, California on the following date: Tuesday, July 12, 2022. At that timepu nkt this legislature will hear protests or objections regarding the annual collection of tax assessments and other matters contained in this resolution. Persons wishing to object to the procedure or the annual levy should lodge a written protest with the town clerk before the time allotted for the public hearing. If a majority object to the charging of an annual fee that is higher than in the previous year, the proposed increase in the allocations should be refrained from. A majority protest is when written protests filed after the conclusion of the hearing and not withdrawn represent property owners who own more than 50% of the assessable property area within the assessment district. 7. That the town clerk is authorized and directed to make the notice required by law by causing a copy of this decision to be published in a newspaper of general circulation in the town of Karlovy Vary not less than 10 days before the appointed date the public Hearing. 8. For any information regarding this process, including information regarding the protest process, please contact the following individuals: CITY OF CARLSBAD, CITY RECIPIENT 1200 CARLSBAD VILLAGE DRIVE, CARLSBAD, CA 92008 and ANNA TAN-GATUE, PROJECT LEADER HARRIS & STAFF PHONE: (800) 827-4901 EXT. 2344 Property owners within the Assessment District may send written protests to the following address: CITY OF CARLSBAD, CITY CLERK 1200 CARLSBAD VILLAGE DRIVE, CARLSBAD, CA 92008 PASSED, APPROVED AND ACCEPTED at an Ordinary Session of the City Council of the City of Carlsbad on May 24, 2022 by the following Vote: YES: Hall, Blackburn, Bhat-Patel, Acosta, Norby. No None. ABSENT: None. RELEASE DATE: July 1, 2022 City of Karlovy Vary | City Council 07/01/2022 CN 26702

DECISION OF THE CITY OF CARLSBAD NO. 2022-114 AN RESOLUTION OF THE CITY COUNCIL FOR THE CITY OF CARLSBAD, CALIFORNIA INITIALIZING PROCEEDINGS, APPROVING THE INTERIM ENGINEERING REPORT FOR THE 2022-23 FISCAL YEAR AND SCHEDULING A PUBLIC HEARING FOR JULY 12, 2022 FOR THE ANNUAL REVIEW IN REPORT AND COUNTRYSIDE DISTRICT NO. 1, A SPECIAL ASSESSMENT DISTRICT WHILE the City Council for the City of Carlsbad, California previously established a special assessment district under the provisions of the California Streets and Highways Code Section 22500 et seq., known as the Street Lighting and Landscaping District Designated No. 1 of the City of Carlsbad (“Rating District”); and WHEREAS the Rating District is an existing Rating District in which no increase in ratings is proposed as defined in Article XIIID of the California Constitution (Proposition 218) and the Proposition 218 Omnibus Implementation Act (California Government Code Section 53750 et seq.). , and is therefore exempt from the procedures and requirements of Proposition 218 under Article XIIID, Section 5, Subsection (a) of the California Constitution; and WHEREAS the City Council wishes to initiate a process to provide for the annual collection of tax amounts for fiscal year 2022-23 to cover the annual cost of maintenance of improvements defined as existing street lighting, medium landscaping and street trees (“ Improvements” ), within the assessment district; and WHEREAS a preliminary engineer’s report (the “Report”) has been prepared and will be submitted to the City Council and attached as Exhibit A as required by law and the City Council’s desire to proceed with the annual filing process; and

WHILE the improvements to be retained must consist of all originally identified and approved improvements plus certain new and additional improvements; and

WHILE the City Council has carefully examined and reviewed the report submitted and is satisfied with all the points and documents contained therein and satisfied itself that the preliminary assessments have been appropriately distributed with the benefits obtained from the improvements to be retained as in the report set out. THEREFORE IT IS NOW RESOLVED by the City Council for the City of Carlsbad, California as follows: 1. That the above recitations are true and correct.

2. That public interest and expediency so require and it is the intention of this Legislative Body to collect and collect estimates of the annual costs and expenses of servicing and/or maintaining the improvements for the assessment district with the improvements in general pay as follows: the maintenance of certain street lighting improvements, street trees and median landscaping improvements as set forth and described in the report. The proposed new improvements to be serviced and maintained generally through new developments within the assessment district are described as follows: the maintenance of certain additional street lighting improvements and additional landscaping improvements, including the replacement of street trees and the median landscaping improvements, all as set out and described in the report. 3. That the improvements will directly benefit properties within the assessment district boundaries previously designated by the Legislature as the area to benefit from the improvement, as identified and referenced in the boundary map previously approved by the City Council, a copy of which resides in the town clerk’s office and is open to the public and bears the name of that assessment district. 4. That the improvements to Harris & Personnel directed to prepare and submit the report, which generally includes: A. Plans and specifications describing the general nature, location and extent of improvements within the assessment district; B. A chart for the appraisal district showing the area and properties proposed for appraisal; C. An estimate of the cost of servicing and/or maintaining the Improvements to the Assessment District for the fiscal year beginning July 1, 2022 and ending June 30, 2023; D. An assessment of the estimated cost of servicing and/or maintenance, assessment of the net amount for all assessable lots and/or packages within the assessment district in relation to the benefits received. 5. That the submitted report be provisionally approved and ordered to be placed in the town clerk’s office as a permanent record and remain open for public inspection. Reference is made to the report for a full and detailed description of the improvements to be retained, the boundaries of the assessment precinct and all zones within it, and the proposed assessments on assessable properties and parcels within the assessment precinct. All tax bills for the Street Lighting Improvement, Street Tree Improvement, and Middle Landscaping Improvement zones remain the same as last year, and any new tax bills added to the tax schedule will be calculated at the same unit rates as last year. 6. It is hereby announced that a public hearing is scheduled for 5:00 p.m. at the City Council Chambers at 1200 Carlsbad Village Drive in Carlsbad, California on the following date: Tuesday, July 12, 2022. At that time, this Legislature will hear protests or objections regarding the annual collection of tax assessments and other matters therein decision included. Persons wishing to object to the procedure or the annual levy should lodge a written protest with the town clerk before the time allotted for the public hearing. If a majority object to the charging of an annual fee that is higher than in the previous year, the proposed increase in surcharge apart. A majority objection exists if written protests submitted after the conclusion of the hearing and not withdrawn represent property owners who own more than 50% of the assessable property area within the assessment district. 7. That the town clerk be authorized and directed to make the notice required by law by causing a copy of this order to be published in a general circulation newspaper in the city of Karlovy Vary not less than 10 days before the day te set for the public hearing. 8. For all information related to this proceeding, including information regarding the protest procedure, please contact the following individuals: CITY OF CARLSBAD, CITY CLERK 1200 CARLSBAD VILLAGE DRIVE, CARLSBAD, CA 92008 and ANNA TAN-GATUE, PROJECT LEADER HARRIS & STAFF PHONE: (800) 827-4901 EXT. 2344 Property owners within the Assessment District may send written protests to the following address: CITY OF CARLSBAD, CITY CLERK 1200 CARLSBAD VILLAGE DRIVE, CARLSBAD, CA 92008 PASSED, APPROVED AND ACCEPTED at an Ordinary Session of the City Council of the City of Carlsbad on May 24, 2022 by the following Vote: YES: Hall, Blackburn, Bhat-Patel, Acosta, Norby. No None. ABSENT: None. RELEASE DATE: July 1, 2022 City of Karlovy Vary | City Council 07/01/2022 CN 26701

SALES NOTICE OF TRUSTEE TS No. CA-21-892931-BF Order No.: 210464395-CA-VOI YOU ARE IN DEFAULT ACCORDING TO A TRUST CUSTOMER DATED 07/11/2005. UNLESS YOU TAKE MEASURES TO PROTECT YOUR PROPERTY IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED ANY EXPLANATION ABOUT THE NATURE OF THE PROCEEDING AGAINST YOU, YOU SHOULD CONTACT AN ATTORNEY. A public auction sale to the highest bidder for cash, a bank check drawn on a state or national bank, a check drawn on a state or federal credit union, or a check drawn on a state or federal savings and credit union, or savings association or savings bank, as defined in Section 5102 of the of the Treasury Code and authorized to conduct business in that state is held by a duly appointed trustee. The sale is made, but without any representation or warranty, express or implied, as to title, possession or encumbrance for payment of the remaining principal amount of the Note(s) secured by the Deed of Trust, including interest and default charges thereon, as provided for in the Notes, Advances, subject to the terms of the Deed of Trust, interest thereon, fees, charges and expenses of the Trustee in respect of the aggregate amount (as at the date of the initial posting of the Notice of Sale) are reasonably expected to be set out below. The amount may be higher on the day of sale. BENEFICIARY MAY CHOOSE TO BID LESS THAN THE TOTAL AMOUNT DUE. Trustees: GREGORY L. CUFF AND ZOSIMA R. CUFF, HUSBAND AND WIFE AS JOINT TENANTS Recorded 7/12/2005 as Instrument #2005-0586814 of Official Records at the SAN DIEGO County Recorder’s Office, California ; Date of sale: 07/25/2022 at 10:00 a.m. Place of sale: At the entrance of the East County Regional Center at the statue, located at 250 E. Main St., El Cajon, CA 92020 Other Cost: $632,918.67 Claimed Property Address is: 4569 AVENIDA PRIVADO, OCEANSIDE, CA 92057 Appraiser Packet Number: 160- 610-70-00 NOTICE TO PROSPECTIVE BIDDERS: If you are considering bidding on this mortgage, you should be aware ar the risks of bidding in an escrow auction. You are bidding on a lien, not the property itself. Placing the highest bid at an escrow sale does not automatically entitle you to ownership of the property for free. You should also be aware that the lien being auctioned may be a sublien. If you are the winning bidder at the auction, you are or may be responsible for paying off any liens overriding the lien being auctioned before you can obtain clear ownership of the property. You are encouraged to investigate the existence, priority and size of any outstanding liens that may exist on this property by contacting the county registry office or a title insurance company, who may charge you a fee for this information. If you consult any of these resources, be aware that the same lender can hold more than one mortgage or deed of trust on the property. NOTICE TO OWNER: The sale date set forth in this notice of sale may be postponed one or more times by the mortgagee, beneficiary, trustee, or a court pursuant to Section 2924g of the California Civil Code. The law requires that information about escrow sale deferrals be made available to you and the public as a courtesy to those i who are not present at the sale. If you would like to know if your sale date has been postponed and, if applicable, the rescheduled time and date for the sale of this property, you can call 916-939-0772 for information on the escrow sale or this one Visit Internet website http://www.qualityloan.com using the file number assigned to this foreclosure by the trustee: CA-21-892931-BF. Information about postponements of very short duration or close to the planned sale may not be immediately reflected in the telephone information or on the website. The best way to verify the move information is to attend the scheduled sale. NOTICE TO RENTERS: You may have a right to purchase this property after the escrow auction under California Civil Code Section 2924m. If you are an “eligible renter-buyer” you can buy the property if you get the last and highest bid in the escrow auction. If you are an “eligible bidder” you may be able to purchase the property if you beat the last and highest bid at the escrow auction. There are three steps to exercising this purchase right. First, 48 hours after the date of the Escrow sale, you may call 916-939-0772 or visit this Internet site http://www.qualityloan.com using the file number assigned to this foreclosure by the Escrow: CA-21-892931-BF to find the date the escrow sale occurred, the amount of the last and highest bid, and the escrow address. Second, you must send a written letter of intent to bid for the trustee to receive no later than 15 days after the trustee is sold. Third, must en you place a bid for the trustee to receive it no later than 45 days after the trustee is sold. If you believe that you may qualify as an “Eligible Renter” or “Eligible Bidder,” you should consider contacting an attorney or appropriate real estate professional immediately for guidance regarding this potential right to purchase. The undersigned trustee disclaims all liability for any inaccuracies in the address of ownership given herein or other common designations. Where no street or other customary designation is provided, directions to the location of the property may be obtained by sending a written request to the beneficiary within 10 days of the date of first posting of this notice of sale. If the sale is canceled for any reason, even if the trustee is unable to transfer title, the purchaser is only entitled to a refund of the monies paid to the trustee upon sale. This is the buyer’s sole and exclusive remedy. Buyer shall have no further recourse against the trustor, trustee, beneficiary, beneficiary’s agent, or beneficiary’s attorney. If you were previously discharged by bankruptcy, you may have been relieved of personal liability for that loan. In this case, this letter serves only to exercise the rights of the debenture holders against the property. Date: Quality Loan Service Corporation 2763 Camino Del Rio S San Diego, CA 92108 619-645-7711 Information Only NOT for Sale (866) 645-7711 Ext. 5318 Quality Loan Service Corp. TS No.: CA-21-892931-BF IDSPub #0179244 07/01/2022 07/08/2022 07/15/2022 CN 26700

TS 099461-CA APN: 216-220-38-00 NOTICE OF SALES OF TRUST IMPORTANT NOTICE TO OWNER: YOU ARE IN DEFAULT AS PER A CUSTOMER OF TRUST DATED 07/09/2012. UNLESS YOU TAKE MEASURES TO PROTECT YOUR PROPERTY IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED ANY EXPLANATION OF THE NATURE OF THE PROCEEDING AGAINST YOU, YOU SHOULD CONTACT AN ATTORNEY ON 8/8/2022 1:00 PM, CLEAR RECON CORP, as duly appointed trustee pursuant to and pursuant to the 7/16 recorded trust agreement /2012 as instrument no. 2012-0410495 of Official Records in the Office of the County Recorder of San Diego County, State of CALIFORNIA Executed by: ELIAS PEREZ AND RACHEL PEREZ, TRUSTEE OR THEIR TRUST SUCCESSORS UNDER THE PEREZ LIVING TRUST DATED JULY 7, 1997 WILL BE AT PUBLIC AUCTION TO HIGHEST BIDDER FOR CASH, CASHIER CHECK DROUGHT ON A STATE OR NATIONAL BANK, CHECK DROUGHT DOWN FROM A STATE OR FEDERAL CREDIT UNION, OR CHECK DROUGHT DOWN FROM A STATE OR FEDERAL SAVINGS AND LOAN ASSOCIATION, SAVINGS ASSOCIATION, OR THINGS IN THE SECTION 5102 OF THE FINANCE CODE AND AUTHORIZED TO OPERATE IN THAT STATE; OUTSIDE THE MAIN ENTRANCE OF THE SUPERIOR COURT NORTH COUNTY DIVISION, 325 S MELROSE DR., VISTA, CA 92081, all right, title and interest vested in and now held by property located in said county and state pursuant to said Deed of Trust : SPECIFIED IN THE REFERENCED DEED OF TRUST. The street address and other common designation, if any, of the property described above is alleged to be: 2743 LEVANTE ST, CARLSBAD, CA 92009-8121 if any, shown here. This sale is being made, but without any express or implied agreement or warranty as to title, title, condition or encumbrances, including Fees, Duties and Expenses of the Trustee and trusts created by this Trust Deed to pay the balance principal of the Debenture(s) secured by said Deed of Trust t. The aggregate amount of the unpaid balance of the obligation secured by the property to be sold and reasonably estimated costs, expenses and advances at the time of the initial publication of the notice of sale is: $590,576.52 if the trustee is unable to transfer ownership of an off Therefore, the Successful Bidder’s sole and exclusive remedy shall be the return of any monies paid to the Trustee and the Successful Bidder shall have no other remedy. The beneficiary pursuant to said Deed of Trust has previously signed and transmitted to the undersigned a written notice of default and notice of sale and a written notice of default and sale election. The undersigned or his predecessor caused the said notice of default and election for sale to be registered in the county where the property is located. NOTICE TO PROSPECTIVE BIDDERS: If you are considering bidding on this mortgage, you should understand that there are risks involved in bidding in an escrow auction. You are bidding on a lien, not the property itself. Placing the highest bid at an escrow sale does not automatically entitle you to ownership of the property for free. You should also be aware that the lien being auctioned may be a sublien. If you are the winning bidder at the auction, you are or may be responsible for paying off any liens overriding the lien being auctioned before you can obtain clear ownership of the property. She who encourages you to investigate the existence, priority and size of any outstanding liens that may exist on this property by contacting the county registry office or a title insurance company, who may charge you a fee for this information. If you consult any of these resources, be aware that the same lender can hold more than one mortgage or deed of trust on the property. NOTICE TO OWNER: The sale date set forth in this notice of sale may be moved one or more times by the mortgagee, beneficiary, trustee or a court and Section 2924g of the California Civil Code. The law requires information about escrow sale deferrals to be made available to you and the public as a courtesy to those not present at the sale. If you would like to know if your sale date has been postponed and, if so, the rescheduled time and date for the sale of this property, you can call (844) 477-7869 or visit this Internet website, WWW.STOXPOSTING.COM , at using of the file number 099461-CA assigned to this case. Information about postponements that are of very short duration or occur shortly before the proposed sale may not be immediately reflected in the telephone information or on the Internet website. The best way to verify the move information is to attend the scheduled sale. NOTICE TO RENTERS: Effective January 1, 2021, you may have the right to purchase this property after the escrow auction under California Civil Code Section 2924m. If you are an “eligible renter-buyer”, you can buy the property if you place the last and highest bid at the Treuhänderaukt e achieve. If you are an “eligible bidder” you may be able to purchase the property if you beat the last and highest bid at the escrow auction. There are three steps to exercising this purchase right. First, 48 hours after the date of the Escrow sale, you may call (855) 313-3319 or visit this Internet site www.clearreconcorp.com using the case number 099461-CA assigned to this case to locate the date , on which the trustee’s sale took place, the amount of the last and highest bid and the address of the trustee. Second, you must send a written letter of intent to bid for the trustee to receive no later than 15 days after the trustee is sold. Third, you must place a bid for the trustee to receive it no later than 45 days after the trustee is sold. If you think you may qualify as an “eligible renter” or “eligible bidder,” you should consider contacting an attorney or appropriate real estate professional immediately to discuss this potential to get advice on purchase law. SALES INFORMATION: (844) 477-7869 CLEAR RECON CORP 4375 Jutland Drive San Diego, California 92117 STOX 932805_099461-CA 7/1/2022, 7/8/2022, 7/15/2022 CN 26699

TS 097144-CA APN: 145-052-08-00 NOTICE OF SALES OF TRUST IMPORTANT NOTICE TO OWNER: YOU ARE IN DEFAULT AS PER A TRUST CUSTOMER DATED 03/17/2005. UNLESS YOU TAKE MEASURES TO PROTECT YOUR PROPERTY IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED AN EXPLANATION OF THE NATURE OF THE PROCEEDING AGAINST YOU, YOU SHOULD CONTACT AN ATTORNEY. On 7/18/2022 at 1:00 p.m., CLEAR RECON CORP, as duly appointed trustee under and pursuant to the Deed of Trust, recorded 4/5/2005 as Instrument No. 2005-0272574 of Official Records at the Office of the County Recorder of San Diego County, State of California Executed By: JOSEFINA RIVERA RIOJAS, A SINGLE WOMAN IS SELLING AT PUBLIC AUCTION TO THE HIGHEST BIDDER FOR CASH, CASH CHECK DRAWN ON A STATE OR NATIONAL BANK, A CHECK DRAWN BY A STATE OR FEDERAL CREDIT UNION , OR A CHECK DRAWN FROM A STATE OR FEDERAL SAVINGS AND LOAN ASSOCIATION, SAVINGS ASSOCIATION, OR BANKS LISTED IN SECTION 5102 OF THE FINANCE CODE AND AUTHORIZED TO TRANSACT BUSINESS IN THAT STATE; OUTSIDE THE MAIN ENTRANCE OF THE SUPERIOR COURT NORTH COUNTY DIVISION, 325 S MELROSE DR., VISTA, CA 92081, all right, title and interest vested in and now held by property located in said county and state pursuant to said Deed of Trust : SPECIFIED IN THE REFERENCED DEED OF TRUST. The address and other common denomination, if any, of the property described above are alleged to be: 1442 PAPIN STREET, OCEANSIDE, CA 92054, CA 92054. The undersigned Trustee disclaims liability for any inaccuracies in the address and other common denomination, if any, shown herein. This sale is made, but without express or implied agreement or G any warrant of title, possession, condition or encumbrance, including fees, charges and expenses of the Trustee and the trusts created by this Trust Deed to pay the balance principal of the debenture(s) secured by said Deed of Trust. The aggregate amount of the unpaid balance of the property to be sold by the secured obligation and reasonable estimated costs, expenses and advances as of the date of initial posting of the notice of sale: $314,366.66. If the trustee is unable to transfer the property for any reason, the trustee’s sole and exclusive remedy shall be of the Successful Bidder the return of monies paid to the Trustee and the Successful Bidder shall have no further recourse. The beneficiary pursuant to said Deed of Trust has previously signed and transmitted to the undersigned a written notice of default and notice of sale and a written notice of default and sale election. The undersigned or his predecessor caused the said notice of default and election for sale to be registered in the county where the property is located. NOTICE TO PROSPECTIVE BIDDERS: If you are considering bidding on this mortgage, you should understand that there are risks involved in bidding in an escrow auction. You are bidding on a lien, not the property itself. Placing the highest bid at an escrow sale does not automatically entitle you to ownership of the property for free. You should also be aware that the lien being auctioned may be a sublien. If you are the winning bidder at the auction, you are or may be responsible for paying off any liens overriding the lien being auctioned before you obtain clear ownership of the property can be obtained. You are encouraged to investigate the existence, priority and size of any outstanding liens that may exist on this property by contacting the county registry office or a title insurance company, who may charge you a fee for this information. If you consult any of these resources, be aware that the same lender can hold more than one mortgage or deed of trust on the property. NOTICE TO OWNER: The sale date set forth in this notice of sale may be postponed one or more times by the mortgagee, beneficiary, trustee, or a court pursuant to Section 2924g of the California Civil Code. This is what the law requires in information about trustee deferrals of sale to be made available to you and the public as a courtesy to those not present at the sale. If you would like to know if your sale date has been postponed and, if so, the rescheduled time and date for the sale of this property, you can call (844) 477-7869 or visit this Internet website, WWW.STOXPOSTING.COM, using the file number 097144-CA assigned to this case. Information about postponements that are of very short duration or occur shortly before the proposed sale may not be immediately reflected in the telephone information or on the Internet website. The best way to verify the move information is to attend the scheduled sale. NOTICE TO RENTERS: Effective January 1, 2021, you may have the right to purchase this property after the escrow auction under California Civil Code Section 2924m. If you are an “eligible renter-buyer” you can buy the property if you last and achieve the highest bid in the trustee auction. If you are an “eligible bidder” you may be able to purchase the property if you beat the last and highest bid at the escrow auction. There are three steps to exercising this purchase right. First, 48 hours after the date of the Escrow sale, you may call (855) 313-3319 or visit this Internet site www.clearreconcorp.com using the case number 097144-CA assigned to this case to locate the date , on which the trustee’s sale took place, the amount of the last and highest bid and the address of the trustee. Second, you must send a written letter of intent to bid for the trustee to receive no later than 15 days after the trustee is sold. Third, you must place a bid for the trustee to receive it no later than 45 days after the trustee is sold. If you believe that you may qualify as an “Eligible Tenant” or “Eligible Bidder,” you should consider contacting an attorney or appropriate real estate professional immediately for guidance regarding this ding of this potential purchase right. SALES INFORMATION: (844) 477-7869 CLEAR RECON CORP 4375 Jutland Drive San Diego, California 92117 STOX 932565_097144-CA 06/17/2022, 06/17/2022, 06/24/2022, 07/01/2022 CN 26670

LIEN SALE THE FOLLOWING VEHICLE IS SOLD AT LIEN SALE ON 07/14/2022 AT 3971 AIRWAY RD, SAN DIEGO CA 92154 AT 9:00 AM 13, FRHT, CASCADIA, DS, 5QEZ246, CA, 1FUJGLDR2DSBR0108 07/01/2022 CN 26705

APPLICATION FOR PUBLIC SALE NOTIFICATION IS HEREBY NOTIFIED that the contents of the following storage units will be publicly auctioned to enforce storage lien. The online auction will take place on Friday, July 8, 2022 at 1:00 p.m. Online Auction Location: www.storagetreasures.com. Warehouse address: 1566 E. Valley Parkway, Escondido, CA 92027. Terms are CASH ONLY! Valley Rose Self Storage reserves the right to refuse any bid or cancel the auction. The following entities can include electronic items, furniture & Household items unless otherwise noted. Kyla Clayton – G-319 06/24, 07/01/2022 CN 26694

NOTICE OF PETITION TO Administration Estate of KEITH ALLAN WILSON Case# 37-2022-00020013-PR-LA-CTL by Keith Allan Wilson. A probate application was filed by Melissa Ann Wilson in the Superior Court of California, County of San Diego. The Petition for Probate requests that Melissa Ann Wilson be appointed as a personal representative to administer the testator’s estate. The petition seeks authority to administer the estate under the Independent Administration of Estates Act. (This power allows the personal representative to take many actions without obtaining court approval. However, prior to taking certain very important actions, the personal representative must notify interested persons unless they have waived notification or the proposed action consented. ) The power of self-government will be granted unless a data subject objects to the application and justifies why the court should not grant the power of attorney. A hearing on the application will be held in this court as follows: Date: August 10, 2022; Time: 1:30 p.m.; in Dept.: 502. Court Address: 1100 Union St., San Diego CA 92101, Central Courthouse. Court appearances may be either in person or virtually, unless the court orders otherwise. Virtual appearances must be made via the department’s Microsoft Teams (“MS Teams”) video link; or by calling the department’s MS Teams conference phone number and using the assigned conference ID number. MS Teams video conferencing links and phone numbers can be found at www.sdcourt.ca.gov/ProbateHearings. If you object to the grant of the motion, you should appear at the hearing and explain your objections or submit written objections to the court prior to the hearing. Your appearance may be in person or through your attorney take place. If you are a creditor or a conditional trustee of the deceased, you must file your claim with the court and send a copy to the court-appointed personal representative within (1) four months from the date of the first issuance of letters to a general personal representative , as defined in Section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under Section 9052 of the California Probate Code. Other California laws and legal authorities may affect your rights as a creditor. You may want to consult an attorney knowledgeable of California law. You can consult the file kept by the court. If you are a person interested in the estate, you may file a request for special notice (Form DE-154) with the court for the filing of an inventory and appraisal of the estate’s assets or an application or account as provided in Probate Code Section 1250. An application on special notice is available from the clerk of the court. Applicant’s Attorney: Joshua D. Tucker, Esq. 10531 4S Commons Dr. #158 San Diego CA 92127 Telephone: 619.458.3482 06/24, 07/01, 07/08/2022 CN 26691

NOTICE OF PUBLIC SALE BY COMPETITION On July 12, 2022 at 10:00 am at 3231 Waring Court Suite P, Oceanside, California, the personal property referenced in this notice will be sold by tender. • 15 filing cabinets • 17 chairs & Stool • 1 Canon Copier • 22 Framed Photo Wall Art • 5 Tables • 3 Desks • 1 Wheelchair • 2 Medical Examination Tables • 1 AMSCO Eagle Ten Sterilizer • 1 Bathroom Scale • 3 ESI IVX Phones S Class Phone System • 4 Dell Monitors • 5 Dell PCs & Keyboards &

mouse • 1 Dell printer • 2 AT&T modems/routers • 1 D-Link router • 4 power strips • 2 refrigerators • 60 boxes & sorted unpackaged Office & Medical Services, Stationery & Garbage Can • 2 Blood Pressure Monitors • 1 Credit Card Machine • 1 Paper Shredder • Patient Records (approx. 20-4 ft. Shelves & 19 File Boxes for Medical Records • Wheeled Tool Box • 1 Oxygen Tank on Wheels 06/24/2022, 07/01/2022 CN 26690

NOTICE TO QUALIFIED COMMERCIAL CONTRACTORS Subject to terms prescribed by the undersigned, Balfour Beatty Construction invites subcontractors to submit concurrent prequalification criteria along with bids for the following project: MiraCosta College Community College, Oceanside, CA MiraCosta Community College Project # 04215 BALFOUR BEATTY JOB NUMBER: 16850000 ALL BELOW LISTED TRADE (hereinafter “Subcontractors”) are being invited to submit offers for a “BEST VALUE” Trade Subcontractor for the following works: BP #10 Site Concrete BP #11 Landscape & Irrigation BP #12 Roofing BP #13 Sheet Metal BP #14 Ceramic Tiles BP #15 Housing Works BP #16 Floors BP #17 Painting BP #18 Specialties BP #19 Structural Concrete BP #20 Rough Carpentry BP #21 Masonry BP #22 Window Blinds BP #23 Specialty Door System BP #24 Signage & Graphics **Balfour Beatty is the design-build contactor for this MiraCosta Community College project. DESCRIPTION OF WORK: MiraCosta Community College District successfully passed Measure MM to fund much-needed capital improvement projects across their campus in North County, San Diego. The new Arts & The work on the media building and slope stabilization will be located in the area of ​​the existing OC1-C car park near the existing administration building. This project will support the expansion and relocation of the arts/media program to this new facility. The project is divided into 2 separate phases (see site logistic plans) with separate DSA numbers. This should allow the slope stabilization work to begin before the construction of the new culture/media building. Balfour Beatty is seeking the award and contract with the trading companies listed in Schedule 1. Phases #1 and #2 will be awarded and commissioned within 90 days of the offer due date. In phase 2, after A reconciliation process with DSA backcheck comments was carried out with participating subcontractors at the end of the bid. BIDING DOCUMENTS: The bid documentation will be available electronically beginning June 20, 2022: B UILDING CONNECTED BIDDING DEADLINE: Bids will be submitted electronically or delivered only at the following location: Balfour Beatty Construction 1 Barnard Drive Oceanside, CA 92056 July 21, 2022 12:00 am PRE-BID JOB WALK: {DELETE THIS PARAGRAPH IF THERE IS NO MANDATORY PRE-BID CONFERENCE} There will be two (2) Pre-Bid Conferences of which attendance at one (1) is recommended, on Wednesday , June 22, 2022 at 11:00 a.m. and July 7, 2022 at 10:00 a.m. Subcontractor bidders are strongly encouraged to attend this meeting. LICENSE REQUIREMENTS: The successful bidder must have a current and active contractor license required to carry out the scope specified in the relevant tender package at the time of bidding: Balfour Beatty and MiraCosta College encourage participation from small, disadvantaged, minority-owned businesses, Women and Service/Disability Veterans (S/D/M/F/DVBEs) and are committed to nurturing a diverse pool of firms for our construction programs. The work described in the contract is public work governed by Section 1771 of the California Labor Code. No contractor or subcontractor, at any level, shall be named in any bid for any part of this project, or participate in the execution of any part of this project, unless registered with the Department of Industrial Relations in accordance with Sections 1725.5 and 1771.1 of the registered in the Labor Code. Contractors and subcontractors must use the DIR’s Enhanced Electronically Certified Payroll (eCPR) system to provide Commissioner-Certified Payslips ( CPRs). Contractors and subcontractors who have submitted PDF copies of their CPRs for previous projects must also start using the new system. ALL CONTRACTORS AND SUBCONTRACTORS MUST BE REGISTERED WITH THE INDUSTRIAL RELATIONS DEPARTMENT (DIR) AT THE TIME OF THE OFFER. Visit http://www.dir.ca.gov/public-works/publicworks.html to register for more information. This project is subject to monitoring and enforcement of compliance by the Department of Labor Relations. 24.6., 1.7.22 CNS-3598149# CN 26689

SUBPARTMENT (CITACION JUDICIAL) CASE No. (Número del Caso): 37-2021-00050322-CL-CO-NC NOTICE TO DEFENDANT: (AVISO AL DEMANDADO): RICHARD L. THIBAUT and DOES 1 through 10, inclusive. YOU ARE SUE BY THE PLAINTIFF: (LO ESTÀ DEMANDANDO EL DEMANDANTE):   THE VILLAGES OF RANCHO DEL ORO ASSOCIATION, INC., a non-profit mutual company. NOTE! They were sued. The court may rule against you without you being heard unless you respond within 30 days. Read the information below. You have 30 CALENDAR DAYS after you are served with this subpoena and the legal documents to file a written response with that court and have a copy served on the plaintiff. A letter or phone call will not protect you. Your written response must be in proper legal form if you want the court to hear your case. There may be a court form that you can use in your response. You can find these court forms and additional information at the California Courts Online Self-Help Center (www.courtinfo.ca.gov/selfhelp), at your County Law Library, or at your nearest courthouse. If you cannot pay the filing fee, ask the court clerk for a fee waiver form. If you fail to submit your response on time, you may lose the case by default, and your wages, money, and property may be confiscated by the court without further warning. Other legal requirements apply. You may want to call an attorney right away. If you don’t know a lawyer, you can call a Lawyer Referral Service. If you cannot afford a lawyer, you may be entitled to free legal advice from a nonprofit legal aid program. You can find these nonprofit groups on the California Legal Services website ste (www.lawhelpcalifornia.org), at the California Courts’ Online Self Help Center (www.courtinfo.ca.gov/selfhelp), or by contacting your local court or district attorney’s association. NOTE: The court has a statutory lien on waived fees and costs in settlement or arbitration awards of $10,000 or more in a civil proceeding. Case. The court lien must be paid before the court dismisses the case. ¡AVISO! Lo han demandado. If no answer dentro de 30 days, la corte puede decide en su contra sin escuchar su versión. Lea la information a continuación. Tiene 30 DÍAS DE CALENDARIO después de que le entreguen esta citación y papeles legales para presentar una respuesta por escrito en esta corte y hacer que se entregue una copia al demandante. Una carta o una llamada telefónica no lo protegen. Su respuesta por escrito tiene que estar en formato legally correcto si desea que procesen su caso en la corte. It is possible que haya un formulario que usted pueda usar para su respuesta. Puede encontrar estos formularios de la corte y más information en el Centro de Ayuda de las Cortes de California (www.sucorte.ca.gov), en la biblioteca de leyes de su condado o en la corte que le quede más cerca. Si no puede pagar la cuota de presentación, pida al secretario de la corte que le dé un formulario de exención de pago de cuotas. Si no presenta su respuesta a tiempo, puede perder el caso por incumplimiento y la corte le podrá quitar su sueldo, dinero y bienes sin más advertencia. Hay other legal requirements. It is advisable to que llame a un abogado inmediatamente. Si no conoce a un abogado, puede llamar a un servicio de remisión a abogados. Si no puede pagar a un abogado, it posible que cumpla con los requisites para obtener servicios legales gratuitos de un programa de servicios legales sin fines de lucro. Puede encontrar estos grupos sin fines de lucro en el site web de California Legal Services, (www.lawhelpcalifornia.org), en el Centro de Ayuda de las Cortes de California, (www.sucorte.ca.gov) o poniéndose en contacto con la corte o el colegio de abogados locales. AVISO: Por ley, la corte tiene derecho a reclamar las cuotas y los costos exentos por imponer un gravamen sobre cualquier recuperación de $10.000 ó más de valor recibida mediante un acuerdo o una concesión de Arbitje en un caso de derec ho bourgeois. Tiene que pagar el gravamen de la corte antes de que la corte pueda desechar el caso. The name and address of the court is: (El nombre y dirección de la corte es): Superior Court of California County of San Diego 325 S. Melrose Dr. Vista CA 92081 Name, address and telephone number of plaintiff’s attorney, or plaintiff without attorney, is: (El nombre, la dirección y el número de teléfono del abogado del demandante, o del demandante que no tiene abogado, es): Mark T. Guithues, Esq. #199217 Jeffrey W. Speights, Esq. #265206 Community Legal Advisors Inc 509 N. Coast Highway Oceanside CA 92054 Phone: 760.529.5211 Date: (Fecha) 12/01/2021 Clerk of (Secretario), A. Carini, Assistant (Adjunto) NOTICE TO EDIT PERSON: You will served as an individual. 06/24, 07/01, 07/08, 07/15/2021 CN 26686

SUBMISSION (Paternity – Custody and Maintenance) CITACIÓN (Paternidad – Custodia y Manutención) CASE NUMBER: (Número de caso) 22FL002253N NOTICE TO RESPONDER AVISO AL DEMANDADO: Shannon Westley You have been sued. Read the information below and on the next page. Lo han demandado. Lea la information a continuación y en la página siguiente. Applicant: El nombre del demandante: Juron Junior You have 30 calendar days after you are served with this subpoena and petition to file a response (Form FL-220 or FL-270) with the court and have a copy served on the applicant. A letter, phone call or court appearance will not protect you. If you do not submit your response in a timely manner, the court may make orders that affect your custody of your children. They can also be ordered to pay child support and attorneys’ fees and costs. Contact an attorney immediately for legal advice. Get help finding an attorney at the California Courts Online Self-Help Center (www.courts.ca.gov/selfhelp), the California Legal Services website (www.lawhelpca.org), or contact your local attorney Bar Association. NOTE: The injunction remains in effect against each parent until the application is dismissed, a judgment is rendered, or the court makes further orders. This order is enforceable anywhere in California by any law enforcement officer who has received or seen a copy of it. FEE WAIVE: If you cannot pay the application fee, ask the clerk for a fee waiver form. The court may order you to pay back all or part of the fees and costs that the court waived from you or the other party. Tiene 30 dias de calendario después de habir recibido la entrega legal de esta Citación y Petitición para presentar una Res puesta (Formulario FL-220 or FL-270) ante la corte y efectuar la entrega legal de una copia al demandante. Una carta o llamada telefónica o una audiencia de la Corte no basta para protegerlo. Si no presenta su Respuesta a tiempo, la corte puede dar ordenes que afecten la custodia de sus hijos. La Corte Tamb ién le puede ordenar que pague manutención de los hijos, y honorarios y costos legales. Para asesoramiento legal, póngase en contacto de immediate con un abogado. Please refer to the Centro de Ayuda de las Cortes de California (www.sucorte.ca.gov), the California Legal Services Web site (www.lawhelpca.org), or contact us at el colegio de abogados de su condado. AVISO: La órden de protection que aparecen continuará en vigencia en cuanto a cada parte hasta que se emita un fallo final, se despida la petición o la corte dé otras órdenes. Cualquier agencia del orden public que haya recibido o visto una copia de estas orden puede hacerla acatar en cualquier lugar de California. EXENCIÓN DE CUOTAS: Si no puede pagar la cuota de presentación, pida al secretario un formulario de exención de cuotas. La corte puede ordenar que usted pague, ya sea en parte o por completo, las cuotas y costs de la corte previamente exentos a petición de usted o de la otra parte. The name and address of the court is: (El nombre y dirección de la corte son:) North County Regional Center 325 S. Melrose Dr. Vista CA 92081 The name, address and telephone number of the applicant’s attorney, or the applicant without attorney, are: (El nombre, la dirección y el número de teléfono del abogado del demandante, o del demandante si no tiene abogado, son:) Brianna S. Davis, Esq. 314893 LAW OFFICE OF BRIANNA S. DAVIS, APC 350 Tenth Ave., Ste 100 San Diego CA 92101 858.866.9672 Date (Fecha): March 1, 2022 Clerk, by (Secretario, por) W. Condit, Deputy (Asistente) STANDARD injunction (descent – custody and sub receipt) ORDEN DE RESTRICCIÓN ESTÁNDAR (Paternidad – Custodia y Manutención) Effective immediately, you and any other party are prohibited from removing the minor child or children from the state or applying for a passport this lawsuit seeks to establish a parent-child relationship or custody by order without the prior written consent of all other parties or a court order. This injunction will be effective against the applicant if he or she files the application and against the respondent if the subpoena and application are served on him or her in person OR if he or she waives it and accepts service. This injunction will remain in effect until the judgment is entered, the application is dismissed, or the court makes other orders. This order is enforceable anywhere in California by any law enforcement officer who has received or seen a copy of it. En forma immediate, usted y cada otra parte tienen prohibido llevarse del estado a los hijos menores para quienes esta acción court procura establecer una relación entre hijos y padres o una orden de custodia, ni pueden solicitar un pasaporte para los mismos, sin el consentimiento previo por escrito de cada otra parte o sin una orden de la corte. Esta orden de restricción entrará en vigencia para el demandante una vez presentada la petición, y para el demandado una vez que éste reciba la notificación personal de la Citación y Petición, o una vez que renuncie su derecho a recibir dicha notificación y se dé por notificado . Esta orden de restricción continuará en vigencia hasta que se emita un fallo final, se despida la petición o la corte dé otras órdenes. Cualquier agencia del orden publico que haya recibido o visto una copia de esta orden puede hacerla acatar en cualquier lugar de California. NOTE – ACCESS TO CHEAP HEALTH INSURANCE Do you need o someone in your household affordable health insurance? Then you should apply for Covered California. Covered California can help lower the cost of quality, affordable healthcare. Visit www.coveredca.com for more information. Or call Covered California at 1-800-300-1506. AVISO—ACCESO A SEGURA DE SALUD MÁS ECONOMICO Necessita seguro de salud a un costo asequible, ya sea para usted o alguien en su hogar? Si es asi, p You are asked to present with Covered California. Covered California lo puede ayudar a reducir al costo que paga por seguro de salud asequible y de alta calidad. For more information, visit www.coveredca.com. Contact Covered California at 1-800-300-0213. OTHER: Temporary Emergency Orders (Ex Parte), Statement by Alicia Hieb Regarding Respondent’s Notification of Ex Parte Hearing, Statement on Notification and Service of Application for Emergency Temporary Orders (Ex Parte), Ex Parte Application and – Order, Petitioner’s Statement on Ex Parte Application and Order, Subpoena, Hearing Notice, Application for Child Custody and Support, Temporary Emergency Orders (Ex Parte), Application for Child Custody and Support, Notice of Assignment of Case, Statement by Alicia Hieb regarding DCSS Hearing Respondent Notice, Hearing Notice, Hearing Notice, Minor Child Custody and Support Application, Family Court Services Screening Form, Hearing Notice. HEARING NOTICE TO; Defendant Shannon Westley A COURT HEARING WILL BE HELD AS FOLLOWS: Date: July 20, 2022 Time: 9:00 a.m. Division: 17 Superior Court of California County of San Diego 325 S. Melrose Dr. Vista CA 92081 WARNING to the person being served with the order Request: The court may make the requested orders without you if you do not file a response to the request for an order (Form FL-320) to provide a copy to the other parties at least nine days before the hearing (unless the court orders a shorter period of time). has) and appear at the hearing. (See Form FL-320-INFO for more information.) 06/17, 06/24, 07/01, 07/08/2022 CN 26683

AMENDED ORDER TO SHOW REASON FOR NAME CHANGE CASE NO. 37-2022-00010979-CU-PT-CTL TO ALL INTERESTED PERSONS: Applicant: Gabrial Omar Anaya filed a motion in this court for a name change order as follows: a . Current name: Gabriel Omar Anaya Proposed name change: Gabriel Omar Anaya. THE COURT orders that all persons interested in this matter appear before this court at the hearing set out below to state, if any, reasons why the application for a name change should not be granted. Any person objecting to the name changes described above must file a written and reasoned objection at least two days before the scheduled hearing and appear at the hearing to explain why the motion should not be granted. If an objection is not raised in writing in good time, the court can grant the application without an oral hearing. HEARING NOTICE: July 20, 2022 at 8:30 a.m. in Dept. 61 of the Superior Court of California, 330 W. Broadway, San Diego CA 92101, Hall of Justice. NO HEARING WILL BE HELD ON THE ABOVE DATE; ATTACHMENT TO PROOF OF REASON FOR NAME CHANGE REQUEST (JC FORM #NC-120) NO HEARING WILL BE HELD ON THE DATE SPECIFIED IN THE PROOF OF REASON REQUEST. The court reviews the submitted documents from the date specified in the Order Proving Reasons for Name Change (JC Form No. NC-120). If all requirements for a name change are met by the specified date and no timely written objection is received (required at least two court days prior to the specified date), the name change request (JC Form #NC-100 ) will be granted without a hearing. A certified copy of the decision to grant the application will be sent to de sent to the petitioner. If all the requirements are not met by the specified date, the court will send the applicant a written order with further instructions. If a timely appeal is filed, the court will set a remote hearing date and email the parties with further instructions. A SURVEYED OBJECT AGAINST THE NAME CHANGE MUST ENTER IN WRITTEN OBJECTION AT LEAST TWO COURT DAYS (excluding weekends and holidays) BEFORE THE SCHEDULED DATE. Do not come to court on the appointed date. The court will notify the parties by mail of a future remote hearing date. Any request for a name change of a minor signed by only one parent, this attachment, along with the request and the taking of evidence order, must be served on the other non-signing parent and proof of service must be filed with the court. IT IS SO ORGANIZED. Date: 6/6/2022 Michael T. Smyth Judge, Superior Court. 6/10, 6/17, 6/24, 7/1/2022 CN 26647

SUPERIOR COURT OF CALIFORNIA, COUNTY OF SAN DIEGO APPLICANT: Gustavo Isaac Sa vs INTERVIEWER: Paola Andrea Sa REQUEST: Other: Enforcement of Divorce Decree & change after the judgment. Supporting Facts: Attachment 10. CASE #: 19FL008822C HEARING NOTICE TO: Paola Andrea Sa, Defendant A COURT HEARING WILL BE HOLDED AS FOLLOWS: Date: August 30, 2022 Time: 9:00 am Division: 601 Court Address: 1100 Union St., San Diego CA 92101 Hearing Appearance Information: Visit www.sdcourt.ca.gov for more information. WARNING to the person served with the order request: The court may make the requested orders without you if you do not file a Statement of Response to the Order Request (Form FL-320) and serve a copy to the other parties at least nine days before the hearing (es unless the court has ordered a shorter period) and appear at the hearing. (See Form FL-320-INFO for more information.) (Forms FL-300-INFO and DV-400-INFO contain information for completing this form). REQUESTS TO ORDER OTHER REQUESTED ORDERS: The petitioner requests that the divorce decree be amended to include omitted community assets (college savings accounts). The assets must be added to FL 345. The applicant also seeks to enforce the divorce decree and ask the clerk to sign the title deed awarded to the applicant on behalf of the respondent. FACTS TO SUPPORT the orders I have requested are listed below. Applicant’s statement in support of the order, receipts and exhibits have been filed with the clerk and are available for inspection. 06/10, 06/17, 06/24, 07/01/2022 CN 26644

ORDER TO SHOW REASON FOR NAME CHANGE CASE NO. 37-2022-00020182-CU-PT-NC TO ALL INTERESTED PERSONS: Applicant: China Renee Kellner filed a name change order with this court as follows: a. Current name: China Renee Kellner, Proposed name change: China Renee Morgan. THE COURT orders that all persons interested in this matter appear before this court at the hearing set out below to state, if any, reasons why the application for a name change should not be granted. Any person objecting to the name changes described above must file a written and reasoned objection at least two days before the scheduled hearing and appear at the hearing to explain why the motion should not be granted. If an objection is not raised in writing in good time, the court can grant the application without an oral hearing. HEARING NOTICE: On July 12, 2022 at 8:30 a.m., at Dept. D25 of the Superior Court of California, 325 S Melrose Dr., Vista CA 92081, North County Division. NO HEARING WILL BE HELD ON THE ABOVE DATE; ATTACHMENT TO PROOF OF REASON FOR NAME CHANGE REQUEST (JC FORM #NC-120) NO HEARING WILL BE HELD ON THE DATE SPECIFIED IN THE PROOF OF REASON REQUEST. The court reviews the submitted documents from the date specified in the Order Proving Reasons for Name Change (JC Form No. NC-120). If all requirements for a name change are met by the specified date and no timely written objection is received (required at least two court days prior to the specified date), the name change request (JC Form #NC-100 ) will be granted without a hearing. A certified copy of the application granting decision will be sent to the Pe tents sent. If all the requirements are not met by the specified date, the court will send the applicant a written order with further instructions. If a timely appeal is filed, the court will set a remote hearing date and email the parties with further instructions. A RESPONDENT TO OBJECT TO THE NAME CHANGE MUST FILE AN OBJECTION IN WRITING AT LEAST TWO COURT DAYS (excluding weekends and holidays) BEFORE THE SPECIFIED DATE. Do not come to court on the appointed date. The court will notify the parties by mail of a future remote hearing date. Any request for a name change of a minor signed by only one parent, this attachment, along with the request and the taking of evidence order, must be served on the other non-signing parent and proof of service must be filed with the court. IT IS SO ORGANIZED. Filing date: 2022-05-27 James E. Simmons Jr. Judge of Superior Court. 6-10, 6-17, 6-24, 7-01-2022 CN 26634

Fictitious Company Name Statement #2022-9014748 Filed June 28, 2022 with the County of San Diego Recorder/County Clerk. Fictitious company name(s): A. Vnnyl; B. Vinyl Vintage. Location: 115 Blue Ash Ct., Encinitas CA 92024 San Diego. Postal address: Same. Registrant Information: 1. Anne Marie Moffatt, 134 Phoebe St., Encinitas CA 92024. This business is managed by: Individual. The registrant first began trading under the above names from: 2017-08-20 S/Anne Marie Moffatt, 07-01, 07-08, 07-15, 2022-07-22 CN 26718

Fictitious Company Name Statement #2022-9012760 Filed June 3, 2022 with County of San Diego Recorder/County Clerk. Fictional company name(s): A. Cozease. Location: 2281 Ulric St. #&, San Diego CA 92111 San Diego. Postal address: Same. Registrant Information: 1. Mobile Business Providers LLC, 2281 Ulric St. #7, San Diego CA 92111. This business is operated by: Limited Liability Company. Registrant first started doing business under the above names as of: Not yet started S/Sarah Quesada, 07/01, 07/08, 07/15, 07/22/2022 CN 26717

Fictitious Company Name Statement #2022-9014156 Filed June 22, 2022 with the County of San Diego Recorder/County Clerk. Fictional company name(s): A. Silvergate Rancho Bernardo; B. Silvergate. Location: 140 Lomas Santa Fe Dr. #103, Solana Beach CA 92075 San Diego. Postal address: Same. Registrant Information: 1. SRB1, LLC, 140 Lomas Santa Fe Dr. #103, Solana Beach CA 92075. This business is operated by: Limited Liability Company. The registrant first started trading under the above names from: 07/01/2020 S/Gilles Giauffer, 07/01, 07/08, 07/15, 07/22/2022 CN 26716

Fictitious Company Name Statement #2022-9014682 Filed June 28, 2022 with the County of San Diego Recorder/County Clerk. Fictional company name(s): A. A perfect carpet repair. Address: 270 N. El Camino Real #183, Encinitas CA 92024 San Diego. Postal address: Same. Registrant Information: 1. William Lewis Thomas, 270 N. El Camino Real #183, Encinitas CA 92024. This business is managed by: Individual. Registrant first started doing business under the above names from: Not yet started S/William Lewis Thomas, 07/01, 07/08, 07/15, 07/22/2022 CN 26715

Fictitious Company Name Statement #2022-9014636 Filed June 27, 2022 with County of San Diego Recorder/County Clerk. Fictional company name(s): A. Hernandez Landscape Services. Location: 357 Apollo Dr., Vista CA 92084 San Diego. Postal address: Same. Registrant information: 1. Dagoberto B. Hernandez, 357 Apollo Dr., Vista CA 92084; 2. Esahin L. Hernandez, 357 Apollo Dr., Vista CA 92084; 3. Jose Luis Hernandez, 357 Apollo Dr., Vista CA 92084. This store is operated by: General Partnership. The registrant first began trading under the above names from: 06/01/2022 S/Dagoberto Hernandez, 07/01, 07/08, 07/15, 07/22/2022 CN 26714

Fictitious Company Name Statement #2022-9014650 Filed June 27, 2022 with County of San Diego Recorder/County Clerk. Fictitious company name(s): A. DLF Vehicle Services. Address: 1930 S. Coast Hwy #206, Oceanside CA 92054 San Diego. Postal address: Same. Registrant Information: 1. Michael G. Doan, A Professional Corporation, 1930 S. Coast Hwy #206, Oceanside CA 92054. This company is operated by: Corporation. The registrant first began trading under the above names from: 01/01/2022 S/Michael G. Doan, 07/01, 07/08, 07/15, 07/22/2022 CN 26708

Fictitious Company Name Statement #2022-9005268 Filed March 03, 2022 with County of San Diego Recorder/County Clerk. Fictional company name(s): A. All in Good Taste. Location: 2053 Acacia Dr., San Marcos CA 92078 San Diego. Postal address: Same. Registrant Information: 1. Loree Hill Luther, 2053 Acacia Dr., San Marcos, CA 92078. This business is managed by: Individual. First commencement of business under the above names by the registrant: 03/03/2022 S/Loree Hill Luther, 07/01, 07/08, 07/15, 07/22/2022 CN 26707

Fictitious Company Name Statement #2022-9014210 Filed June 22, 2022 with County of San Diego Recorder/County Clerk. Fictional company name(s): A. Garden by the Sea Paper. Address: 1758 Kennington Rd., Encinitas CA 92024 San Diego. Postal address: Same. Registrant Information: 1. Nicole Mashburn, 1758 Kennington Rd., Encinitas CA 92024. This business is managed by: Individual. Registrant first began doing business under the above names as of: Not yet started S/Nicole Mashburn, 07/01, 07/08, 07/15, 07/22/2022 CN 26704

Fictitious Company Name Statement #2022-9013936 Filed June 17, 2022 with the County of San Diego Recorder/County Clerk. Fictitious company name(s): A. Clarity Communications. Location: 265 Venetia Way, Oceanside CA 92057 San Diego. Postal address: Same. Registrant Information: 1. Clarity Consulting Group, 265 Venetia Way, Oceanside CA 92057. This business is operated by: Corporation. The registrant first began trading under the above names from: 04/01/2022 S/Abigail Hart, 07/01, 07/08, 07/15, 07/22/2022 CN 26698

Fictitious Company Name Statement #2022-9014135 Filed June 21, 2022 with the County of San Diego Recorder/County Clerk. Fictional company name(s): A. Bitter Taste Sweet Health Acupuncture and Herbs. Address: 2335 Caringa Way #23, Carlsbad CA 92009 San Diego. Postal address: Same. Registrant Information: 1. Shellby House, 2335 Caringa Way #23, Carlsbad CA 92009. This business is operated by: Individual. The registrant first started doing business under the above names from: 21/06/2022 S/Shellby House, 24/06, 01/07, 08/07, 15/07/2022 CN 26697

Fictitious Company Name Statement #2022-9013971 Filed June 21, 2022 with County of San Diego Recorder/County Clerk. Fictional company name(s): A. Metzger + Willard Inc. a V&A Consulting Engineers Company; B. Metzger + Willard Inc. Registered office: 8600 Hidden River Pkwy #550, Tampa FL 33637 Hillsborough. Postal address: Same. Registrant Information: 1. V&A Consulting Engineers Inc., 1000 Broadway #320, Oakland CA 94607. This business is operated by: Corporation. The registrant first began trading under the above names from: 2022-06-13 S/Debra L. Kaye, 2022-06-24, 2022-07-07, 07-08, 2022-07-15 CN 26695

Fictitious Company Name Statement #2022-9013155 Filed June 8, 2022 with County of San Diego Recorder/County Clerk. Fictional company name(s): A. Life Inspired Focused Environments Designs. Location: 2211 Whisper Wind Ln., Encinitas CA 92024 San Diego. Postal address: Same. Registrant Information: 1. Cynthia A.C. Houck, 2211 Whisper Wind Ln., Encinitas CA 92024. This business is operated by: Individual. The registrant first began trading under the above names from: 03/01/2005 S/Cynthia AC Houck, 06/24, 07/01, 07/08, 07/15/2022 CN 26693

Fictitious Company Name Statement #2022-9013635 Filed June 14, 2022 with County of San Diego Recorder/County Clerk. Fictional company name(s): A. Papas Gone Wild Tacos and Specialty Catering. Location: 3261 Buena Hills Dr., Oceanside CA 92056 San Diego. Postal address: Same. Registrant Information: 1. Rosanne Maestas, 3261 Buena Hills Dr., Oceanside CA 92056. This business is managed by: Individual. The registrant first started trading under the above names on: 01/01/2019 S/Rosanne Maestas, 06/17, 06/24, 07/01, 07/08/2022 CN 26685

Fictitious Company Name Statement #2022-9013652 Filed June 14, 2022 with County of San Diego Recorder/County Clerk. Fictional company name(s): A. Canopy Threads. Location: 4079 Governor Dr. #3001, San Diego CA 92122 San Diego. Postal address: Same. Registrant Information: 1. Canopy Threads LLC, 4079 Governor Dr. #3001, San Diego CA 92122. This business is operated by: Limited Liability Company. Registrant first began doing business under the above names as of: Not yet commenced S/Katherine Jones 17/06, 24/06, 01/07, 08/07/2022 CN 26684

Fictitious Company Name Statement #2022-9012785 Filed June 3, 2022 with County of San Diego Recorder/County Clerk. Fictional company name(s): A. Reyon and Master Cat Puddah Speak. Address: 3412 Las Vegas Dr., Oceanside CA 92054 San Diego. Postal address: Same. Registrant Information: 1. Laurie Anderson, 3412 Las Vegas Dr., Oceanside CA 92054. This business is operated by: Individual. First commencement of business under the above names by the registrant: 09/01/2012 S/Laurie Anderson, 06/17, 06/24, 07/01, 07/08/2022 CN 26680

Fictitious Company Name Statement #2022-9013344 Filed June 10, 2022 with County of San Diego Recorder/County Clerk. Fictional company name(s): A. Bright Rhythm. Location: 2382 Carol View Dr. #F111, Cardiff CA 92007 San Diego. Postal address: Same. Registrant Information: 1. Bright Rhythm LLC, 2382 Carol View Dr., #F111, Cardiff by the Sea CA 92007. This business is operated by: Limited Liability Company. The registrant first began trading under the above names from: 05/05/2022 S/Dan Norcross, 06/17, 06/24, 07/01, 07/08/2022 CN 26679

Fictitious Company Name Statement #2022-9013173 Filed June 09, 2022 with County of San Diego Recorder/County Clerk. Fictional company name(s): A. Able Bodies Fitness. Location: 2637 Regent Rd., Carlsbad CA 92010 San Diego. Postal address: Same. Registrant Information: 1. Allison Able, 2637 Regent Rd., Carlsbad CA 92010. This business is managed by: Individual. The registrant first began trading under the above names from: 06/09/2022 S/Allison Able, 06/17, 06/24, 07/01, 07/08/2022 CN 26678

Fictitious Company Name Statement #2022-9011834 Filed May 23, 2022 with the County of San Diego Recorder/County Clerk. Fictional company name(s): A. All Cats Hospital. Location: 2210 Running Spring Pl., Encinitas CA 92024 San Diego. Mailing Address: PO Box 230948, Encinitas, CA 92023. Registrant Information: 1. Lynn Ann Yut, 2210 Running Spring Pl., Encinitas, CA 92024. This business is managed by: Individual. The registrant first began trading under the above names from: 25/10/1991 S/Lynn Ann Yut, 17/06, 24/06, 01/07, 08/07/2022 CN 26676

Fictitious Company Name Statement #2022-9013016 Filed June 7, 2022 with County of San Diego Recorder/County Clerk. Fictional company name(s): A. Vamooz. Address: 5046 Los Morros Way #91, Oceanside CA 92057 San Diego. Postal address: Same. Registrant Information: 1. Ceja Capital LLC, 5046 Los Morros Way #91, Oceanside CA 92057. This business is operated by: Limited Liability Company. The registrant first started doing business under the above names from: Not yet started S/Martin Ceja, 17/06, 24/06, 01/07, 08/07/2022 CN 26675

Fictitious Company Name Statement #2022-9012952 Filed June 6, 2022 with County of San Diego Recorder/County Clerk. Fictional company name(s): A. Well Living with Maddie. Address: 2061 Village Park Way, Encinitas CA 92024 San Diego. Postal address: Same. Registrant Information: 1. Madison M. Wilkerson, 2061 Village Park Way, Encinitas, CA 92024. This business is managed by: Individual. The Registrant first began trading under the above names from: 06/06/2022 S/Madison M. Wilkerson, 06/17, 06/24, 07/01, 07/08/2022 CN 26674

Fictitious Company Name Statement #2022-9013056 Filed June 8, 2022 with County of San Diego Recorder/County Clerk. Fictional company name(s): A. North County Team. Location: 518 Moonlight Dr., San Marcos CA 92069 San Diego. Postal address: Same. Registrant Information: 1. Palizban Realty Group Inc., 518 Moonlight Dr., San Marcos CA 92069. This business is operated by: Corporation. Registrant first started doing business under the above names on: Not yet started S/Behrooz Palizban, 17/06, 24/06, 01/07, 08/07/2022 CN 26672

Fictitious Company Name Statement #2022-9012810 Filed June 3, 2022 with County of San Diego Recorder/County Clerk. Fictional company name(s): A. Let’s do Hair. Address: 2120 Jimmy Durante Blvd. No. 101, Del Mar CA 92014 San Diego. Postal address: Same. Registrant Information: 1. Lloyd Trimble, 2120 Jimmy Durante Blvd. #101, Del Mar CA 92014. This business is operated by: Individual. The registrant first started business under the above names on: Not yet started S/Lloyd Trimble, 17/06, 24/06, 01/07, 08/07/2022 CN 26671

Fictitious Company Name Statement #2022-9011500 Filed May 17, 2022 with the County of San Diego Recorder/County Clerk. Fictional company name(s): A. The Talent Agency. Address: 660 Cypress Hills Dr. #100, Encinitas CA 92024 San Diego. Postal address: Same. Registrant Information: 1. Tenfold Social Training Inc., 660 Cypress Hills Dr. #100, Encinitas CA 92024. This business is operated by: Corporation. First established business under the above names by registrant: 19/10/2012 S/Stacy Zapar, 10/06, 17/06, 24/06, 01/07/2022 CN 26655

Fictitious Company Name Statement #2022-9012975 Filed June 7, 2022 with County of San Diego Recorder/County Clerk. Fictional company name(s): A. Cheeks by Skylar. Location: 264 Turner Ave., Encinitas CA 92024 San Diego. Postal address: Same. Registrant Information: 1. Skylar Sheerman, 264 Turner Ave., Encinitas CA 92024. This business is operated by: Individual. First commencement of business under the above names by the registrant: 06/07/2022 S/Skylar Sheerman, 06/10, 06/17, 06/24, 07/01/2022 CN 26654

Fictitious Company Name Statement #2022-9012884 Filed June 6, 2022 with County of San Diego Recorder/County Clerk. Fictional company name(s): A. Lulu’sCare. Location: 8556 Flanders Dr., San Diego CA 92126 San Diego. Postal address: Same. Registrant Information: 1. Luselva Salmon, 8556 Flanders Dr., San Diego CA 92126. This business is operated by: Individual. First commercial operation under the above names by registrant: 06/06/2022 S/Luselva Salmon, 06/10, 06/17, 06/24, 07/01/2022 CN 26651

Fictitious Company Name Statement #2022-9009694 Filed April 26, 2022 with the County of San Diego Recorder/County Clerk. Fictional company name(s): A. Mezo Beverages LLC; B. Mezo Agave. Address: 211 Fraxinella St., Encinitas CA 92024 San Diego. Postal address: Same. Registrant Information: 1. Mezo Beverages LLC, 211 Fraxinella St., Encinitas CA 92024. This business is operated by: Limited Liability Company. The registrant first started trading under the above names from: 02/01/2022 S/Troy Brajkovich, 06/10, 06/17, 06/24, 07/01/2022 CN 26650

Fictitious Company Name Statement #2022-9012076 Filed May 25, 2022 with the County of San Diego Recorder/County Clerk. Fictional company name(s): A. SD AV Pros; B SD AVTV; C. SD-AVTV professionals; D. SC AV professionals; E. SoCal AV; F.AVSD; G. AV SD. Location: 912 Poppy Ln., Carlsbad CA 92011 San Diego. Mailing Address: 7040 Avenida Encinas #104, Carlsbad CA 92011. Registrant Information: 1. Clark Realty Advisors, 912 Poppy Ln., Carlsbad CA 92011. This business is operated by: Corporation. First commencement of business under the above names by the registrant: 25/05/2022 S/Scott Clark, 10/06, 17/06, 24/06, 01/07/2022 CN 26649

Fictitious Company Name Statement #2022-9012709 Filed June 02, 2022 with County of San Diego Recorder/County Clerk. Fictional company name(s): A. Elevate Biotech. Location: 7895 Vista Higuera, Carlsbad CA 92009 San Diego. Postal address: Same. Registrant Information: 1. Courtney Jackson, 7895 Vista Higuera, Carlsbad CA 92009; 2. Keith Jackson, 7895 Vista Higuera, Carlsbad CA 92009. This business is operated by: Couple. First commencement of business under the above names by the registrant: 05/02/2022 S/Courtney Jackson, 06/10, 06/17, 06/24, 07/01/2022 CN 26648

Fictitious Company Name Statement #2022-9012781 Filed June 3, 2022 with County of San Diego Recorder/County Clerk. Fictional company name(s): A. Student Planet; B. Planetary tours for students; C. San Diego Baja Tours. Address: 7032 Fern Pl., Carlsbad CA 92011 San Diego. Postal address: Same. Registrant Information: 1. Student Planet International LLC, 7032 Fern Pl., Carlsbad CA 92011. This business is operated by: Limited Liability Company. The registrant first began trading under the above names from: 07/11/2020 S/Thomas E. Cox, 06/10, 06/17, 06/24, 07/01/2022 CN 26646

Fictitious Company Name Statement #2022-9011919 Filed May 24, 2022 with the County of San Diego Recorder/County Clerk. Fictional company name(s): A. Hynes Intl. Address: 742 Seabright Ln., Solana Beach CA 92075 San Diego. Postal address: Same. Registrant Information: 1. Spark Matchmaking LLC, 742 Seabright Ln., Solana Beach CA 92075. This business is operated by: Limited Liability Company. The registrant first began trading under the above names from: 03/03/2022 S/Karen Hynes, 06/10, 06/17, 06/24, 07/01/2022 CN 26645

Fictitious Company Name Statement #2022-9011965 Filed May 24, 2022 with the County of San Diego Recorder/County Clerk. Fictional company name(s): A. Steampro LLC. Address: 1036 North Ave., Escondido CA 92026 San Diego. Mailing address: 1234 N. Santa Fe Ave. #142, Vista CA 92083. Registrant Information: 1. Steampro LLC, 1036 North Ave., Escondido CA 92026. This business is operated by: Limited Liability Company. The registrant first began trading under the above names from: 01/01/2022 S/Rafael Baltazar Galicia, 06/10, 06/17, 06/24, 07/01/2022 CN 26643

Fictitious Company Name Statement #2022-9012747 Filed June 3, 2022 with County of San Diego Recorder/County Clerk. Fictional company name(s): A. The Hugging Tree. Address: 3716 Jemez Dr., San Diego CA 92117 San Diego. Postal address: Same. Registrant Information: 1. Madison Lacey Teets, 3716 Jemez Dr., San Diego Ca 92117. This business is managed by: Individual. Registrant first began doing business under the above names as of: Not yet commenced S/Madison Teets 06/10, 06/17, 06/24, 07/01/2022 CN 26642

Fictitious Company Name Statement #2022-9012528 Filed June 1, 2022 with County of San Diego Recorder/County Clerk. Fictitious company name(s): A. Balanceology Accounting. Address: 2001 Valley View Blvd., El Cajon CA 92109 San Diego. Postal address: Same. Registrant Information: 1. Andrea Concepcion Manroe, 2001 Valley View Blvd., El Cajon CA 92109. This business is managed by: Individual. The registrant first started doing business under the above names from: Not yet started S/Andrea Concepcion Manroe, 10/06, 17/06, 24/06, 01/07/2022 CN 26641

Fictitious Company Name Statement #2022-9012584 Filed June 1, 2022 with County of San Diego Recorder/County Clerk. Fictional company name(s): A. True Identity Life Coaching. Address: 311 N. Citrus Ave., Vista CA 92084 San Diego. Mailing Address: PO Box 1461, Vista CA 92085. Registrant Information: 1. Kellers Resources Group, 311 N. Citrus Ave., Vista CA 92084. This company is operated by: Corporation. The registrant first began trading under the above names from: 06/01/2022 S/Brett P. Keller, 06/10, 06/17, 06/24, 07/01/2022 CN 26640

Fictitious Company Name Statement #2022-9012028 Filed May 24, 2022 with the County of San Diego Recorder/County Clerk. Fictional company name(s): A. Leva Apparel. Location: 2628 Rawhide Ln., San Marcos CA 92078 San Diego. Postal address: Same. Registrant Information: 1. Alexandra Marie Fischerstrom, 2628 Rawhide Ln., San Marcos, CA 92078. This business is managed by: Individual. The registrant first began trading under the above names from: 05/01/2020 S/Alexandra Fischerstrom, 06/10, 06/17, 06/24, 07/01/2022 CN 26639

Fictitious Company Name Statement #2022-9011101 Filed May 12, 2022 with the County of San Diego Recorder/County Clerk. Fictional company name(s): A. Williams Motorsport and Transport. Address: 7087 Estrella de Mar Rd. #8B, Carlsbad CA 92009 San Diego. Postal address: Same. Registrant Information: 1. Michael D. Williams, 7087 Estrella de Mar Rd. #8B, Carlsbad CA 92009. This business is operated by: Individual. Registrant first began doing business under the above names as of: Not yet begun S/Michael D. Williams, 06/10, 06/17, 06/24, 07/01/2022 CN 26637

Fictitious Company Name Statement #2022-9012416 Filed May 31, 2022 with the County of San Diego Recorder/County Clerk. Fictional company name(s): A. Sushi Lounge Encinitas. Location: 461 Santa Fe Dr., Encinitas CA 92024 San Diego. Postal address: 5703 Oberlin Dr. #201, San Diego CA 92121. Registrant Information: 1. Tsunami Restaurant Group LLC, 5703 Oberlin Dr. #201, San Diego CA 92121. This business is operated by: Limited Liability Company. The registrant first started trading under the above names from: 05/06/2012 S/Frank Interlandi, 06/10, 06/17, 06/24, 07/01/2022 CN 26636

Fictitious Company Name Statement #2022-9012010 Filed May 24, 2022 with the County of San Diego Recorder/County Clerk. Fictional company name(s): A. Oceanside Ace Hardware; B. Oside Ace hardware. Address: 263 S. Coast Hwy, Oceanside CA 92054 San Diego. Postal address: Same. Registrant Information: 1. LM Enterprises Inc., 263 S. Coast Hwy, Oceanside CA 92054. This business is operated by: Corporation. Registrant first began doing business under the above names as of: Not yet commenced S/Logan J. Higginbotham McEniry, 06/10, 06/17, 06/24, 07/01/2022 CN 26635

Related Posts:

Related Posts:

Who funds the Federal Register?

Who funds the Federal Register?

By law, the board is non-partisan; a maximum of six members may belong to the same political party. Funded by Congressional funds, LSC provides legal services through grants to independent local programs selected through a competitive system.

Is the Federal Register an authority? The Federal Register is published every business day by the Office of the Federal Register (OFR) of the National Archives and Records Administration (NARA). The Federal Register contains: Federal authority regulations. Proposed rules and notices of interest to the public.

Who owns Federal Register?

cover
TypeDaily Official Journal
publisherOffice of the Federal Register
FoundedJuly 26, 1935
languageEnglish

Is the Federal Register official?

Published by the Office of the Federal Register, National Archives and Records Administration (NARA), the Federal Register is the official daily publication for rules, proposed rules, and pronouncements by federal agencies and organizations, as well as executive orders and other Presidential documents.

Who runs the Federal Register?

The Office of the Federal Register, part of the National Archives and Records Administration, publishes regulations in the Federal Register, the official “newspaper” of the federal government, each weekday.

What agency is in charge of the Federal Register?

Published by the Office of the Federal Register, National Archives and Records Administration (NARA), the Federal Register is the official daily publication for rules, proposed rules, and pronouncements by federal agencies and organizations, as well as executive orders and other Presidential documents.

Who prints the Federal Register?

The Federal Register (the federal government’s daily newspaper) is a legal newspaper published each weekday by the National Archives and Records Administration (NARA). The Federal Register contains: Federal Agency Regulations.

How often is the Federal Register printed?

The CFR contains the full and official text of the Agency’s regulations, organized into fifty titles covering broad subject areas. The CFR is updated and published once a year in print, fiche, and electronic formats.

WHO publishes the Federal Register?

In which title of the CFR will you find the OSHA standards quizlet?

In which title of the CFR will you find the OSHA standards quizlet?

OSHA standards appear in the Code of Federal Regulations (CFR). The CFR is divided into titles. OSHA standards are included in Title 29.

What part of the CFR does OSHA’s Maritime Standards contain? Maritime – Guidance for OSHA 29 CFR Part 1919 Accredited Agencies – Using Official OSHA Certification Forms | Occupational Safety and Health Authority.

What are 29 CFR Parts 1915 referred to as?

29 CFR Part 1915 – OCCUPATIONAL HEALTH AND SAFETY STANDARDS FOR SHIPSHIP EMPLOYMENT. C.F.R.

What are 29 CFR Parts 1915 1917 1918 also referred to as?

What are 29 CFR Parts 1915, 1917 and 1918 called? Maritime industry standards.

What is the name of 29 CFR 1910?

29 CFR Part 1910 – OCCUPATIONAL SAFETY AND HEALTH STANDARDS.

In which title of the CFR will you find the OSHA standards?

OSHA standards are published in Title 29 of the Code of Federal Regulations (CFR) and are divided into separate standards for general industry, construction, and marine.

Where can you find the OSHA standards?

Standards can be viewed on OSHA’s Laws and Regulations page at www.osha.gov/law-regs.

In which title of the CFR will you find the OSHA standards quizlet?

OSHA standards appear in the Code of Federal Regulations (CFR). The CFR is divided into titles. OSHA standards are included in Title 29.

What CFR is used for the construction standards given by OSHA quizlet?

OSHA Standard Construction 29 CFR Part 1926.

Where are the OSHA standards for construction and general industry found?

OSHA standards for construction and general industry can be found in Title 29 of the Code of Federal Regulations, with general industry standards listed in Part 1910, Sections 1910.1 through 1910.1450.

What CFR is used for the construction standards given by OSHA?

The final OSHA standard for construction work in confined spaces went into effect on August 3, 2015. The new standard, Subpart AA of 29 CFR 1926, establishes requirements for practices and procedures to protect workers involved in construction activities on a job site with one or more confined spaces.

Is the Federal Register available online from 1936?

Is the Federal Register available online from 1936?

The complete Federal Register from 1936 to the present is now available digitally on GPO’s govinfo. https://www.govinfo.gov/app/collection/FR .

Is the Federal Register available online? Publicly available documents are a preview of the documents that usually appear in the Federal Register the next day. The documents are available online at www.ofr.gov/inspection.

Where can I find old Federal regulations?

HeinOnline is the most comprehensive source for finding older versions of the CFR. Lexis (1981 onwards) and Westlaw (1984 onwards) both provide access to older versions of the CFR.

Where can you locate federal regulations?

You can read the full text of the Federal Register and Code of Federal Regulations (CFR) online, find it in libraries, or purchase it from the Government Printing Office (GPO). The full text of the Federal Register and Code of Federal Regulations (CFR) can be found on the GPO website.

Where can I find old versions of CFR on Westlaw?

In Westlaw, navigate to the All Content tab and select Regulations > Code of Federal Regulations (CFR) > CFR Historical (located in the Tools & Resources panel on the right). Click on the desired year. Westlaw requires a search string to perform the search.

When was the Federal Register first published?

Based on these procedures, the first documents were submitted to the department for publication on March 12, 1936, and the first edition of the Federal Register was published on March 14, 1936. It was sixteen pages.

Can anyone read the Federal Register?

A proposed rule published in the Federal Register notifies the public of a pending rule. Any person or organization can respond directly, either in writing or orally at a hearing. Many agencies also accept comments online or via email. The comment period varies but is typically 30, 60, or 90 days.

Is Code of Federal Regulations available online?

Is Code of Federal Regulations available online?

The Code of Federal Regulations (CFR) is current with the published print version of the CFR. The online version will also be made available when the print editions are published.

Is the CFR available online? The e-CFR is available at www.ecfr.gov.

Is the Code of Federal Regulations an official publication?

The Code of Federal Regulations (CFR) presents the official and complete text of agency regulations in an organized manner in a single publication. The CFR is updated with changes appearing in the daily Federal Register.

How do you cite the Code of Federal Regulations?

Principle 1: The core of a citation of a codified federal regulation consists of three elements: Element (a) – The title number followed by a space and “C.F.R.” (for “Code of Federal Regulations”) followed by a space «e.g.» 20 CFR § 404.260.

Is the Code of Federal Regulations a primary source?

Cases, codes and regulations are primary sources. You can usually access a free version of cases and codes through government resources such as Congress.gov, Regulations.gov, or FDsys.

Where can I find Code of Federal Regulations?

The full text of the Federal Register and Code of Federal Regulations (CFR) can be found on the GPO website. For the Federal Register, you can perform field searches from 1995 to present and search entire issues since 1994. Issues of CFR titles are online for 1996 to present.

Where are government regulations published?

Published by the Office of the Federal Register, National Archives and Records Administration (NARA), the Federal Register is the official daily publication for rules, proposed rules, and pronouncements by federal agencies and organizations, as well as executive orders and other Presidential documents.

What is the title of Code of Federal Regulations?

The Code of Federal Regulations
disciplineadministrative law
languageEnglish
Publication information
publisherOffice of the Federal Register (United States)

How do you site a federal regulation?

Regulations are first published in the Federal Register and later appear in the Code of Federal Regulations (C.F.R.). A typical citation from the CFR begins with the title number followed by the abbreviated reference __C.F.R. __ followed by section and year.

How are federal regulations established?

Typically, a federal agency first proposes a regulation and asks the public for comments. The agency then reviews the public comments and issues a final regulation, which may include revisions responsive to the comments.

How do you cite 21 CFR?

Enter the ordinance title number, then the abbreviation “C.F.R.” Enter a space, then enter the section symbol (§), a space, and the section number. Complete your reference with the year of issue of the CFR. Type a space after the section number, and then type the year of CFR issue in parentheses.